Loading...
HomeMy WebLinkAboutContract Sid CAG-02-177 1997 Edition -Electronic Format AIA Document A101-1997 Standard Form of Agreement Between Owner and Contractor where the basis of payment il a STIPULATED SUM lTHIS DOCU MENT HAS IMPORTANT LEGAL AGREEMENT made as of th,�day of (In words,indicate day,month and year) CONSEQUENCES.CONSULTATION WITH AN ATTORNEY 15 ENCOURAGED WITH BETWEEN the Owner: RESPECT TO ITS COMPLETION OR (Name,address and other information) MODIFICATION.AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY of Renton DOCUMENT MI BE MADE BY USING AIA City 1055 South Grady Way Renton, WA 98055 AIA Document A201-1997,General and the Contractor: Conditions of the Contract for (Name,address and other information) Construction,is adopted in this document by reference.Do not use with other general conditions unless this document is Granquist Construction Company modified. 1478 Retsil Road SE Port Orchard. WA 98366 This document has been approved and endorsed by The Associated General 360.876.2887 Contractors of America. 360.8763095 fax The Project is: (Name and location) Fire Station 12 1209 Kirkland Avenue NE Renton, WA The Architect is: (Name,address and other information) Rice Fergus Miller Architecture and Planning, LLC 262 Fourth Street Bremerton, WA 98337 360.377.8773 360.792.1385 fax ..� The Owner and Contractor agree as follows. ARTICLE 1 THE CONTRACT DOCUMENTS Z*_ ,� + The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, Addenda issued prior to execution of this Agreement, other documents listed in this Agreement and Modifications 01997 AIA® issued after execution of this Agreement;these form the Contract,and are as fully a part of the AIA DOCUMENT A101-1997 Contract as if attached to this Agreement or repeated herein. The Contract represents the OWNER-CONTRACTOR AGREEMENT entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. An enumeration of the Contract The American Institute of Architects Documents,other than Modifications,appears in Article 8. 1735 New York Avenue,N.W. Washington,D.C.20006-5292 ARTICLE 2 THE WORK OF THIS CONTRACT 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, , ® 1997 by The American Institute o Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below.User Document:fs 12 A101.aia--12/312002.AIA License Number 1008538,which expires on 9/3/2003. 1 1110 %IN The Contractor shall fully execute the Work described in the Contract Documents, except to the extent specifically indicated in the Contract Documents to be the responsibility of others. ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 3.1 The date of commencement of the Work shall be the date of this Agreement unless a different date is stated below or provision is made for the date to be fixed in a notice to proceed issued by the Owner. (Insert the date ofcommencement ifit differs from the date of this Agreement or,ifappficable,state that the date will be fixed in a notice to proceed.) Date will be fixed in a notice to proceed. THIS DOCUMENT HAS IMPORTANT LEGAL If, prior to the commencement of the Work, the Owner requires time to file mortgages, CONSEOUENCES.CONSULTATION WITH mechanic's liens and other security interests,the Owners time requirement shall be as follows: AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA 3.2 The Contract Time shall be measured from the date of commencement. DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. 3.3 The Contractor shall achieve Substantial Completion of the entire Work not later than Two Hundred Seventy (270)calendar days from the date of commencement,or as follows: AIA Document A101-1997,General (Insert number of calendar days. Alternatively, a calendar date may be used when coordinated with the date of Conditions of the Contract for commencement. Unless stated elsewhere in the Contract Documents,insert any requirements for earlier Substantial Construction,is adopted in this document Completion ofcertain portions ofthe Work.) by reference.Do not use with other general conditions unless this document is modified. subject to adjustments of this Contract Time as provided in the Contract Documents. (Insert provisions,if any,for liquidated damages relating to failure to complete on time or for bonus payments for This document has been approved and early completion of the Work.) endorsed by The Associated General Liquidated damages relating to faliure to complete on time shall be fixed at One Contractors of America. Hundred Fifty and No/100 Dollars($150.00) per day for cost of inspection. ARTICLE 4 CONTRACT SUM 4.1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor's performance of the Contract. The Contract Sum shall be Three Million One Hundred Twelve Thousand, One Hundred Fifty Four and 54/100 Dollars Dollars ($ 3.112.154.54),subject to additions and deductions as provided in the Contract Documents. 4.2 The Contract Sum is based upon the following alternates,if any,which are described in the Contract Documents and are hereby accepted by the Owner: (State the numbers or other identification of accepted alternates.Ifdecisions on other alternates are to be made by the Owner subsequent to the execution of this Agreement,attach a schedule ofsuch other alternates showing the amount for each and the date when that amount expires) Alternate#1 dated "Provide pre-action fire spinkler system at second floor of building. Alternate#2 dated "Provide metal roof system in lieu of asphalt composition shingle roofing_ Altemate#3 dated "Provide infrared heating system at appaatus bay in lieu of unit heaters. , 4.3 Unit prices,if any,are as follows: 01997 AIAO AIA DOCUMENT AIOI-1997 OWNER-CONTRACTOR AGREEMENT ARTICLE 5 PAYMENTS 5.1 PROGRESS PAYMENTS The American Institute of Architects 1735 New York Avenue,N.W. 5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor Washington,D.C.20006-5292 and Certificates for Payment issued by the Architect,the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the 0 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, ® 1997 by The American Institute o Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below.User Document:fs 12 A101.aia--12/3/2002.AIA License Number 1008538,which expires on 9/3/2003. 2 Contract Documents. 5.1.2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month,or as follows: 5.1.3 Provided that an Application for Payment is received by the Architect not later than the 10thday of a month, the Owner shall make payment to the Contractor not later than the 30th day of the month. If an Application for Payment is received by the Architect after the application date fixed above,payment shall be made by the Owner not later than 30 days after THIS DOCUMENT HAS IMPORTANT LEGAL the Architect receives the Application for Payment. CONSEQUENCES.CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH 5.1.4 Each Application for Payment shall be based on the most recent schedule of values RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF submitted by the Contractor in accordance with the Contract Documents. The schedule of THIS ELECTRONICALLY DRAFTED AIA values shall allocate the entire Contract Sum among the various portions of the Work. The DOCUMENT MAY BE MADE BY U51NGAIA schedule of values shall be prepared in such form and supported by such data to substantiate its DOCUMENT D401. accuracy as the Architect may require. This schedule,unless objected to by the Architect,shall be used as a basis for reviewing the Contractor's Applications for Payment. AIA Document A201-1997,General Conditions of the Contract for 5.1.5 Applications for Payment shall indicate the percentage of completion of each portion Construction,is adopted in this document of the Work as of the end of the period covered by the Application for Payment. by reference.Do not use with other general conditions unless this document is 5.1.6 Subject to other provisions of the Contract Documents,the amount of each progress modified. payment shall be computed as follows: This document has been approved and endorsed by The Associated General 1 Take that portion of the Contract Sum properly allocable to completed Work as Contractors of America. determined by multiplying the percentage completion of each portion of the Work by the share of the Contract Sum allocated to that portion of the Work in the schedule of values,less retainage of Five percent( 5 %). Pending final determination of cost to the Owner of changes in the Work, amounts not in dispute shall be included as provided in Subparagraph 7.3.8 of AIA Document A2oi-1997• .2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction(or,if approved in advance by the Owner,suitably stored off the site at a location agreed upon in writing),less retainage of Five percent( 5%); .3 Subtract the aggregate of previous payments made by the Owner;and .4 Subtract amounts, if any, for which the Architect has withheld or nullified a Certificate for Payment as provided in Paragraph 9.5 of AIA Document A2o1-1997. 5.1.7 The progress payment amount determined in accordance with Subparagraph 5.1.6 shall be further modified under the following circumstances: .1 Add,upon Substantial Completion of the Work,a sum sufficient to increase the total . „ payments to the full amount of the Contract Sum,less such amounts as the Architect shall determine for incomplete Work,retainage applicable to such work and unsettled claims;and 01997 AIA® (Subparagraph 3t8.5 of AIA Document A2ot-1997requires release ofapplicable retainege upon Substantial AIA DOCUMENT A101-1997 Completion of Work with consent ofsurety,ifany.) OWNER-CONTRACTOR AGREEMENT .2 Add,if final completion of the Work is thereafter materially delayed through no fault The American Institute of Architects of the Contractor, any additional amounts payable in accordance with Subparagraph 1735 New York Avenue,N.W. 9.10.3 of AIA Document A2o1-1997. Washington,D.C.20006-5292 0 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 0 1997 by The American Institute o Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below.User Document:fs 12 AIOI.aia--12/3/2002.AIA License Number 1008538,which expires on 9/3/2003. 3 5.1.8 Reduction or limitation of retainage,if any,shall be as follows: (/fit is intended,prior to Substantial Completion of the entire Work,to reduce or limit the reta page resulting from the percentages inserted in Clauses Sr.6.r and 5.1.6.2 above, and this is not explained elsewhere in the Contract Documents,insert here provisions forsuch reduction orh'mitation.) 5.1.9 Except with the Owner's prior approval, the Contractor shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site. 5.2 FINAL PAYMENT THIS DOCUMENT HAS IMPORTANT LEGAL 5.2.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be CONSEOUENCES.CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH made by the Owner to the Contractor when: RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF 1 the Contractor has fully performed the Contract except for the Contractor's THIS ELECTRONICALLY DRAFTED AIA responsibility to correct Work as provided in Subparagraph 12.2.2 of AIA Document DOCUMENT MAY BE MADE BY USING AIA A2o1-1997, and to satisfy other requirements, if any, which extend beyond final DOCUMENT D401. payment;and AIA Document A201-1997,General .2 a final Certificate for Payment has been issued by the Architect. Conditions of the Contract for Construction,is adopted in this document 5.2.2 The Owner's final payment to the Contractor shall be made no later than o days after by reference.Do not use with other P Ym 3 Y general conditions unless this document is the issuance of the Architect's final Certificate for Payment,or as follows: Sixty (60) days modified. after the project completion per RCW and Project Manual and release of liens. This document has been approved and ARTICLE 6 TERMINATION OR SUSPENSION endorsed by The Associated General 6.1 The Contract may be terminated by the Owner or the Contractor as provided in Contractors of America. Article 14 of AIA Document A2o1-1997. 6.2 The Work may be suspended by the Owner as provided in Article 14 of AIA Document A2o1-1997. ARTICLE 7 MISCELLANEOUS PROVISIONS 7.1 Where reference is made in this Agreement to a provision of AIA Document A2o1-1997 or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. 7.2 Payments due and unpaid under the Contract shall bear interest from the date payment is due at the rate stated below, or in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located. (Insert rate ofinterest agreed upon,i(any.) Usury laws and requirements under the Federal Truth in Lending Act,similar state and local consumer credit laws and other regulations at the Owner's and Contractor's principal places ofbusinen the location ofthe Project and elsewhere may affect the validity of this provision. Legal advice should be obtained with respect to deletions or modifications, and also regarding requirements such as written disclosures or waivers.) 7.3 The Owner's representative is: (Name,address and other information) 01997 AIA® AIA DOCUMENT AIOI-1997 Dennis Cull OWNER-CONTRACTOR AGREEMENT City of Renton 1055 South Grady Wax The American Institute of Architects Renton. WA 98055 1735 New York Avenue,N.W. 425.430.6600 Washington,D.C.20006-5292 425.430.6603 fax 1951,0 1915, 1918, 1925, 1937, 1958, by The American Institute o Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below.User Document:fs 12 A101.aia--121312002.AIA License Number 1008538,which expires on 9/312003. 4 7.4 The Contractor's representative is: (Name,address and other information) Cranquist Construction Company 1478 Retsil Road SE Port Orchard,WA 98366 360.876.2887 360.876.3095 fax THIS DOCUMENT HAS IMPORTANT LEGAL 7.5 Neither the Owner's nor the Contractor's representative shall be changed without ten CONSEQUENCES.CONSULTATION WITH days written notice to the other party. AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR 7.6 Other provisions: MODIFICATION.AUTHENTICATION OF Contractor insurance requirements shall be as specified in Section'00800 of Project THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA Manual and Section 00820. DOCUMENT D401. AIA Document A201-1997,General ARTICLE 8 ENUMERATION OF CONTRACT DOCUMENTS Conditions of the Contract for 8.1 The Contract Documents, except for Modifications issued after execution of this Construction,is adopted in this document Agreement,are enumerated as follows: by reference.Do not use with other general conditions unless this document is 8.1.1 The Agreement is this executed 1 modified. g 997 edition of the Standard Form of Agreement Between Owner and Contractor,AIA Document Aioi-1997. This document has been approved and endorsed by The Associated General 8.1.2 The General Conditions are the 1997 edition of the General Conditions of the Contractors of America. Contract for Construction,AIA Document A2o1-1997. The General Conditions AIA Document A201-1997 is modified in Attachment A to this Contract. 8.1.3 The Supplementary and other Conditions of the Contract are those contained in the Project Manual dated October 21. 2002,and are as follows: Document Title Pages Project Manual Renton Fire Department&City of Renton Fire Station 12 dated October 21, 2002. 8.1.4 The Specifications are those contained in the Project Manual dated as in Subparagraph 8.1.3,and are as follows: (Frtherh'st the Specifications here or refer to an exhibit attached to this Agreement.) �E Section Title Pages Please refer to above referenced Project Manual. Table of Contents. ,. T, ,•t 8.1.5 The Drawings are as follows,and are dated unless a different date is shown below: (Eithenbst the Drawings here or refer to an exhibit attached to this Agreem en L) 01997 AJA® AIA DOCUMENT AIOI-1997 Number Title Date OWNER-CONTRACTOR AGREEMENT Please refer to attached Drawing List. The American Institute of Architects 1735 New York Avenue,N.W. 8.1.6 The Addenda,if any,are as follows: Washington,D.C.20006-5292 Number Date Pages One (1) -dated November 4 2002-63 pages 1915, 1925, 1937, 1951, 1958, 1961, 1963, 9 9 74, 1977, 1987, 0 1997 by The mencan nstltute o Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below.User Document:fs 12 AIOI.aia--12/3/2002.AIA License Number 1008538,which expires on 9/3/2003. 5 Two(2)-dated November 11. 2002-84 + 1 revised plan sheet Three(3) dated November 13. 2002- 1 page. Portions of Addenda relating to bidding requirements are not part of the Contract Documents unless the bidding requirements are also enumerated in this Article 8. 8.1.7 Other documents,if any,forming part of the Contract Documents are as follows: (List here any additional documents that are intended to form part of the Contract Documents.AIA Document A2or- THIS DOCUMENT HAS IMPORTANT LEGAL i3w provides that bidding requirements such as advertisement or invitation to bid, Instructions to Bidders,sample CONSEQUENCES.CONSULTATION WITH forms and the Contractor's bid are not part of the Contract Documents unless enumerated in this Agreement. They ATTORNEY IS ENCOURAGED WITH should be listed here onlyifintended to be part of the Contract Documents.) AN RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF This Agreement is entered into as of the day and year first written above and is executed in at THIS ELECTRONICALLY DRAFTED AIA least three original copies, of which one is to be delivered to the Contractor, one to the DOCUMENT MAY BE MADE BY USING AIA Arc ' ct for use in the administration of the Contract,and the In to the Owner. DOCUMENT D401. / AIA Document A201-1997,General Conditions of the Contract for Construction,is adopted in this document OWN ER (signature) CONTRACTOR (signature) y reference.Do not use with other general conditions unless this document is modified. Jesse Tanner, Mayor lC 1Chlq�-� �� �RAN�(1lls� This document has been approved and (Printed name and title) (printed name and title) d, ,p endorsed by The Associated General �•U Contractors of America. ATTEST: Bonnie I. Walton, City Clerk f.V 01997 AIA® AIA DOCUMENT A101-1997 OWNER-CONTRACTOR AGREEMENT The American Institute of Architects 1735 New York Avenue,N.W. Washington,D.C.20006-5292 0 1915, 1918, 1925, 1937, IFSTIEF,-1961, 1963, 9 9 74, 1977, 1987, 0 1997 by The American Institute o Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below.User Document:fs 12 A101.aia--12/312002.AIA License Number 1008538,which expires on 9/3/2003. 6 1997 Edition - Electronic Format AIA Document A201 - 1997 General Conditions of the Contract for Construction TABLE OF ARTICLES 1. GENERAL PROVISIONS 2. OWNER TI-95 DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES.CONSULTATION WITH AN 3. CONTRACTOR ATTORNEY 15 ENCOURAGED WITH RESPECT TO ITS COMPLETION OR 4. ADMINISTRATION OF THE CONTRACT MODIFICATION.AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA 5. SUBCONTRACTORS DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. 6. CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS This document has been approved and endorsed by The Associated General 7. CHANGES IN THE WORK Contractors of America. 8. TIME 9. PAYMENTS AND COMPLETION 10. PROTECTION OF PERSONS AND PROPERTY 11. INSURANCE AND BONDS 12. UNCOVERING AND CORRECTION OF WORK 13. MISCELLANEOUS PROVISIONS 14. TERMINATION OR SUSPENSION OF THE CONTRACT INDEX 9.5.1,10.2.5,13.4.2,13.7,14.1 Acceptance of Nonconforming Work Addenda 9.6.6,9.9.3.12-3 1.1.1,3.0 Acceptance of Work Additional Costs,Claims for 9.6.6,9.8.2,9.9.3,9-10.1,9-10-3;12.3 4.3.4,4.3.5,4.3.6,6.1.1,10.3 Access to Work Additional Inspections and Testing 3.16,6.2.1,12.1 9.8-3,12.2.1,13.5 "W. ,W Accident Prevention Additional Time,Claims for i 4.2.3,10 4-3-4,4-3-7,8-3.2 Acts and Omissions ADMINISTRATION OF THE CONTRACT 3.2,3.3.2,3.12.8,3.18,4.2.3,4.3.8,4.4.1,8.3.1, 3.1-3,4,9.4,9.5 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE » opyrig t 1911, 1915, 1918, 1925, 1937, , 1958, 9 1970, y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 1 Q 0 Advertisement or Invitation to Bid 9.3,949-5,9-7,949.9, 10.2.6,10.3,11.3, 1.11 11.4.7,12,13.4.2,13.5 Aesthetic Effect Architect's Relationship with Subcontractors 4.2.13,4.5.1 1.1.2,4.2.3,4.2.44.2.6,9.6.3,9.6.4,11.4.7 Allowances Architect's Representations 3.8 9-4.2,9.5.1,9.10.1 All-risk Insurance Architect's Site Visits 11.4.1.1 4.2.2,4.2.5,4.2.9,4.3.4 9.4.2,9.5.1,9.9.2, Applications for Payment 9.10.1,13.5 4.2.5,7.3.8,9.2,.9-3,9.4,9.5.1,9.6.3,9.7.1,9.8.5, Asbestos 9.10,11-1.3,14.2-4,14-4.3 10.3.1 Approvals Attorneys'Fees 2.4,3.1.3,3.5,3.10.2,3.12,4.2.7,9.3.2,13.4.2, 3.18.1,9.10.2,10-3.3 13.5 Award of Separate Contracts Arbitration 6.1.1,6.1.2 4.3.3,4.4,4.5.1,4.5.2,4.6,8.3.1,9.7-1,11-4-9, Award of Subcontracts and Other Contracts for THIS DOCUMENT HAS IMPORTANT LEGAL 11.4.10 Portions of the Work CONSEQUENCES.CONSULTATION WITH AN Architect 5.2 ATTORNEY IS ENCOURAGED WITH 4.1 Basic Definitions RESPECT TO ITS COMPLETION OR Architect,Definition of 1.1 MODIFICATION.AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA 4.1.1 Bidding Requirements DOCUMENT MAY BE MADE BY USING AIA Architect,Extent of Authority 1.1-1,1.1-7,5.2.1,11.5.1 DOCUMENT D401. 2.4,3.12.7,4.2,4.3.6,4.4,5.2,6.3,7.1.2,7.3.6, Boiler and Machinery Insurance 7-4,9.2,9-3-1,9.4,9.5,9.8-3,9.10.1, 9.10.3,12.1, 11.4.2 This document has been approved and 12.2.1,13.5.1,13.5.2,14.2.2,14.2.4 Bonds,Lien endorsed by The Associated General Architect,Limitations of Authority and 9.10.2 Contractors of America. Responsibility Bonds,Performance,and Payment 2.1.1,3.3.3,3.12.4,3.12.8,3.12.10,4.1.2,4.2.1, 7.3.6.4,9.6.7,9.10.3,11.4.9,11.5 4.2.2,4.2.3,4.2.6,4.2.7,4.2.10,4.2.12,4.2.13, Building Permit 4.4,5.2.1,7.4,9.4.2,9.6.4,9.6.6 3.7.1 Architect's Additional Services and Expenses Capitalization 2.4,U-4.1-1,12.2.1,13-5.2,13-5.3,14.2.4 1.3 Architect's Administration of the Contract Certificate of Substantial Completion 3-1-3,4.2,4-3-4,44,949-5 9.8.3,9.8.4,9.8.5 Architect's Approvals Certificates for Payment 2.4,3.1.3,3.5.1,3.10.2,4.2.7 4.2.5,4.2.9,9.3.3,9.4,9.5,9.6.1,9.6.6,9.7.1, Architect's Authority to Reject Work 9.10.1,9.10.3,13.7,14.1.1.3,14.2.4 3.5.1,4.2.6,12.1.2,12.2.1 Certificates of Inspection,Testing or Approval Architect's Copyright 13.5.4 1.6 Certificates of Insurance Architect's Decisions 9.10.2,11.1.3 4.2.6,4.2-7,4.2.11,4-2.12,4-2-13,4-3-4,4.4.1, Change Orders 4.4.5,4.4.6,4.5,6.3,7.3.6,7.3.8,8.1.3,8.3.1,9.2, 1.1.1,2.4.1,3.4.2,3.8.2.3,3.11.1,3.12.8,4.2.8, 9.4,9.5.1,9.8.4,9.9-1,13-5.2,14.2.2,14.2.4 4.3.4,4.3.9,5.2.3,7.1,7.2,7.3,8.3.1,9.3.1.1, Architect's Inspections 9.10.3,11.4-1.2,U-4.4,11-4-9,12.1.2 4.2.2,4.2-9,4-34,9-4.2,9.8-3,9.9.2,9.10.1,13.5 Change Orders,Definition of Architect's Instructions 7.2.1 3-2-3,3-3-1,4-2-6,4.2-7,4.2.8,7.4.1,12.1,13-5.2 CHANGES IN THE WORK Architect's Interpretations 3.11,4.2.8,7,8.3-1,9.3-1.1,11-4.9 4.2.111 4.2.12.4.3.6 Claim,Definition of Architect's Project Representative 4.3.1 ~' 4.2.10 Claims and Disputes Architect's Relationship with Contractor P 1.1.2,1.6,3.1.3,3.2.1,3.2.2,3.2-3,3-3.1,3-4.2, 3.2.3,4.3,4.4,4.5,4.6,6.1.1,6.3,7.3.8,9.3.3, 3.5.1,3.7.3,3.10,3.11,3.12,3.16,3.18,4.1.2,4.1.3, 9.10.4,10.3.3 01997 AIA® 4.2,4.3.4,4.4.1,4.4.7,5.2,6.2.2,7,8.3.1,9.2, Claims and Timely Assertion of Claims AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 8, 1925, 11958,937, 1951, 1961, 1963, 1966, 1967, 1970, 1976, 9 y The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 2 4.6.5 Contingent Assignment of Subcontracts Claims for Additional Cost 5.4,14.2.2.2 3.2.3,4.3.4,4.3.5,4.3.6,6.1.1,7.3.8,10.3.2 Continuing Contract Performance Claims for Additional Time 4.3.3 3.2.3,4.3.4,4.3.7,6.1.1,8.3.2,10.3.2 Contract,Definition of Claims for Concealed or Unknown Conditions 1.1.2 4.3.4 CONTRACT, TERMINATION OR Claims for Damages SUSPENSION OF THE 3.2.3,3.18,4.3.1o,6.1.1,8.3-3,9.5.1,9.6-7,10-3.3, 5.4-1.1,11-4.9, 14 11.1.1,11.4.5,11.4.7,14.1.3,14.2.4 Contract Administration Claims Subject to Arbitration 3.1-3,4,9.4,9.5 4.4-1,4-5-1,4.6.1 Contract Award and Execution,Conditions Cleaning Up Relating to 3.15,6.3 3.7-1,3-10,5.2,6.1,11.1.3,11.4.6,11.5.1 Commencement of Statutory Limitation Period Contract Documents,The THIS DOCUMENT HAS IMPORTANT LEGAL 13.7 1.1,1.2 CONSEQUENCES.CONSULTATION WITH AN Commencement of the Work,Conditions Contract Documents,Copies Furnished and Use ATTORNEY IS ENCOURAGED WITH Relating to of RESPECT TO ITS COMPLETION OR 2.2-1,3.2.1,3.4.1,3.7.1,3.10.1,3.12.6,4.3.5,5.2.1, 1.6,2.2.5,5.3 MODIFICATION.AUTHENTICATION OF THIS 5.2.3,6.2.2,8.1.2,8.2.2,8.3-1,11-1, 11-4-1,11-4.6, Contract Documents,Definition of ELECTRONICALLY DRAFTED AIA 11.5.1 1.1.1 DOCUMENT MAY BE MADE BY USING AIA Commencement of the Work,Definition of Contract Sum DOCUMENT D401. 8.1.2 3.8,4.3.4,4.3.5,4.4.5,5.2.3,7.2,7.3,7.4,9.1, Communications Facilitating ontract 9.4.2,9.5.1.4,9.6-7,9.7,10-3.2, This document has been approved and g 11.4.1, 14.2.4, endorsed by The Associated General Administration 14.3.2 Contractors of America. 3.9.1, 4.2.4 Contract Sum,Definition of Completion,Conditions Relating to 9.1 1.6.1,3.4.1,3.11,3.15,4.2.2,4.2.9,8.2,9.4.2,9.8, Contract Time 9.9.1,9.10,12.2,13.7,14.1.2 4.3.4,4.3.7,4.4.5,5.2.3,7.2.1.3,7.3,7.4,8.1.1, COMPLETION, PAYMENTS AND 8.2,8.3.1,9.5.1,9.7,10-3.2,12.1.1, 14.3.2 9 Contract Time,Definition of Completion,Substantial 8.1.1 4.2.9,8.1.1,8.1-3,8.2-3,9.4.2,9.8,9.9.1,9.10.3, CONTRACTOR 9.10-4.2,12.2,13.7 3 Compliance with Laws Contractor,Definition of 1.6.1,3.2.2,3.6,3.7,3.12.10,3.13,4.1.1,4.4.8, 3.1,6.1.2 4.6-4,4.6.6,9.6-4,10.2.2,11-1,11.4,13.1,13.4, Contractor's Construction Schedules 13-5.1,13-5.2,i_3.6,14-1.1,14.2.1.3 1.4.1.2,3.10,3.12.1,3.12.2,4.3.7.2,6.1.3 Concealed or Unknown Conditions Contractor's Employees 4.3-4,8.3.1,10.3 3.3.2,3.4-3,3.8.1,3.9,3-18.2,4.2-3,4.2.6,10.2, Conditions of the Contract 10.3,11.1.1,11-4.7,14.1,14.2.1.1, 1.1.1,1.1.7,6.1.1,6.1.4 Contractor's Liability Insurance Consent,Written 11.1 1.6,3.4.2,3.12.8,3.14.2,4.1.2,4.3.4,4.6.4,9.3.2, Contractor's Relationship with Separate 9.8-5,9.9.1,9-10.219-10.3,11-4-1, 13.2,13.4.2 Contractors and Owner's Forces CONSTRUCTION BY OWNER OR BY 3.12.5,3.14.2,4.2.4,6,11-4.7,12.1.2,12.2.4 SEPARATE CONTRACTORS Contractor's Relationship with Subcontractors 1.1.4,6 1.2.2,3.3.2,3.18.1,3.18.2,5,9.6.2,9.6.7,9.10.2, Construction Change Directive,Definition of 11.4.1.2,11.4.7,11.4.8 g 7,3,1 Contractor's Relationship with the Architect Construction Change Directives 1.1.2,1.6,3.1.3,3.2.1,3.2.2,3.23,3.3.1,3.4.2, 1.1.1,312.82 4.2.8,4.3.9,7.1,7.3,9.3.1.1 3.5.1,3.7.3,3.10,3.11,3.12,3.16,3.18, 4.1.2,4.1.3, Construction Schedules,Contractor's 4.2,4.3.4,4.4.1,4.4.7,5.2,6.2.2,7,8.3.1,9.2, 9-3,949-50-70.8,9.9, 10.2.6,10.3,11.3, 01997 AIA® 1.4-1.2,3-10,3.12.1,3.12.2,4.3.7.2,6.1.3 AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 9 by The'CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/30002. AIA License Number 1008538, which expires on 9/312003. 3 111111110 0 11.4.7,12,13.4.2,13.5 Date of Commencement of the Work, Contractor's Representations Definition of 1.5.2,3.5.1,3.12.6,6.2.2,8.2.1,9.3.3,9.8.2 8.1.2 Contractor's Responsibility for Those Date of Substantial Completion,Definition of Performing the Work 8.1.3 3.3.2,3•i8,4.2.3,4.3.8,5.3.1,6.1.3,6.2,6.3,9.5.1. Day,Definition of 10 8.1.4 Contractor's Review of Contract Documents Decisions of the Architect 1.5.2,3.2,3.7.3 4.2.6,4.2.7,4.2.11,4.2.12,4.2.13,4.3.4,4.4.1, Contractor's Right to Stop the Work 4.4.5,4.4.6,4.5,6.3,7.3.6,7.3.8,8.1.3,8.3.1,9.2, 9.7 9.4,9.5.1,9.8.4,9.9.1,13.5.2,14.2.2,14.2.4 Contractor's Right to Terminate the Contract Decisions to Withhold Certification 4.3.10,14.1 9.4.1,9.5,9.7,14.1.1.3 Contractor's Submittals Defective or Nonconforming Work,Acceptance, 3-10,3-u,3-12,4.2-7,5.2.1,5.2.3,7.3.6,9.2,9.3, Rejection and Correction of 9.8.2,9.8.3,9.9.1,9.1 o.2,9.10.3, 11.1.3,11.5.2 2.3,2.4,3.5.1,4.2.6,6.2.5,9.5.1,9.5.2,9.6.6, THIS DOCUMENT HAS IMPORTANT LEGAL Contractor's Superintendent 9.8.2,9.9.3,9.10.4,12.2.1,13.7.1.3 CONSEOUENCES.CONSULTATION WITH AN 3.9,10.2.6 Defective Work,Definition of ATTORNEY IS ENCOURAGED WITH Contractors Supervision and Construction 3.5.1 RESPECT TO ITS COMPLETION OR Procedures Definitions MODIFICATION.AUTHENTICATION OF THIS 1.2.2,3.3,3.4,3.12.10,4.2.2,4.2-7,4.3.3,6.1.3, 1.1,2.1.1,3.1,3.5.1,3.12.1,3.12.2,3.12.3,4.1.1, ELECTRONICALLY DRAFTED AIA 6.2.4,7.1.3,7.3.4,7.3.6,8.2,10,12,14 4.3-1,5.1,6.1.2,7.2.1,7.3.1,7.3.6,8.1, 9.1,9.8.1 DOCUMENT MAY BE MADE BY USING AIA Contractual Liability Insurance Delays and Extensions of Time DOCUMENT D401. 11.1.1.8,11.2,u.3 3.2.3,4.3.1,4.3.4,4.3.7,4.4.5,5.2.3,7.2.1,7.3.1, This document has been approved and Coordination and Correlation 7.4-1,7.5.1,8.3,9.5.1,9.7.1,10.3.2, 1o.6.1,14.3.2 endorsed by The Associated General 1.2,1.5.2,3.3.1,3.10,3.12.6,6.1.3,6.2.1 Disputes Contractors of America. Copies Furnished of Drawings and 4.1.4,4.3,4.4,4.5,4.6,6.3,7.3.8 Specifications Documents and Samples at the Site 1.6,2.2-5,3-11 3.11 Copyrights Drawings,Definition of 1.6,3.17 1.1.5 Correction of Work Drawings and Specifications,Use and 2.3,2.4,3.7.4,4.2.1,9.4.2,9.8.2,9.8.3,9.9.1, Ownership of 12.1.2,12.2,13.7-1.3 1.1.1,1.3,2.2.5,3.11,5.3 Correlation and Intent of the Contract Effective Date of Insurance Documents 8.2.2,11.1.2 1.2 Emergencies Cost,Definition of 4.3-5, 10.6,14-1.1.2 7.3.6 Employees,Contractor's Costs 2.4,3.2.3,3.7.4,3.8.2,3.15.2,4.3,5.4.2,6.1.1, 3.3.2,3.4-3,3.8.1,14.1 34.2.1 4.2.3,4.2.6,10.2, 10.3,11.1.1,11.4.7,14.1,14.2.1.1 6.2.3,7.3.3.3,7.3.6,7.3.7,7.3.8,9.10.2,10.3.2, Equipment,Labor,Materials and 10.5,n.3,B-4,12.1,12.2.1,12.2-4,13.5,14 1.1.3,1.1.6,3.4,3.5.1,3.8.2,3.8.3,3.12,3.13,3.15.1, Cutting and Patching 4.2.6,4.2-7,5.2.1,6.2.1,7.3.6, 9.3-2,9-3.3, 6.2.5,3.14 Damage to Construction of Owner or Separate 9.5-1.3,9.10.2,10.2.1,10.2-4,14.2.1.2 d Progress ofth Work g P Execution and Progress of the Work Contractors 1.1.3,1.2.1,1.2.2,2.2.3,2.2.5,3.1,3.3,3.4,3.5,3.7, 3.14.2,6.2.4,9.2.1-5,10.2.1.2,10.2-5,10.6,im, 3.10,3.12,3.14,4.2.2,4.2.3,4.3.3,6.2.2,7.1.3, U-4,12.2.4 7.3.4,8.2,9.5,9.9.1,10.2,10.3,12.2,14.2,14.3 Damage to the Work Extensions of Time 3.14.2,9.9.1,10.2.1.2,10.2-5,10.6,11.4,12.2.4 3.2.3,4.3.1,4.3-4,4-3-7,4-4-5,5.2.3,7.2.1,7.3, �2$nr Damages,Claims for • • - • ,w 7.4-1,9.5-1,9.7.1,10-3.2,1o.6.1,14.3.2 : 3.2.3,3.18,4.3.10,6.1.1,8.3.3,9.5.1,9.6.7,10.3.3, Failure of Payment 11.1.1,u.4.5,11.4.7,14.1.3,14.2.4 Damages for Delay 4-3.6,9-5-1-3,9-7,9.10.2,14.1-1.3,14.2.1.2,13.6 g y Faulty Work 01997 AIA® 6.1.1,8.3-3,9.5.1.6,9.7,10-3.2 AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 11925,911, 1915, 1918, 1951, 1987, by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/312002. AIA License Number 1008538, which expires on 9/312003. 4 (See Defective or Nonconforming Work) INSURANCE AND BONDS Final Completion and Final Payment 11 4-2-1,4.2-9,4-3.2,9.8.2,9.10,11.1.2,11.1.3,11.4.1, Insurance Companies,Consent to Partial 11.4.5,12.3.1,13.7,14.2.4,14.4.3 Occupancy Financial Arrangements,Owner's 9.9.1,11.4.1.5 2.2.1,13.2.2,14.1-1.5 Insurance Companies,Settlement with Fire and Extended Coverage Insurance 11.4.10 11.4 Intent of the Contract Documents GENERAL PROVISIONS 1.2.1,4.2.7,4.2.12,4.2.13,7.4 1 Interest Governing Law 13.6 13.1 Interpretation Guarantees(See Warranty) 1.2.3, 1.4,4.1.1,4.3.1,5.1,6.1.2,8.1.4 Hazardous Materials Interpretations,Written 10-2.4,10.3,10.5 4.2.11,4.2.12,4-3.6 THIS DOCUMENT HAS IMPORTANT LEGAL Identification of Contract Documents joinder and Consolidation of Claims Required CONSEQUENCES.CONSULTATION WITHAN 1.5.1 4.6.4 ATTORNEY IS ENCOURAGED WITH Identification of Subcontractors and Suppliers judgment on Final Award RESPECT TO ITS COMPLETION OR 5.2.1 4.6.6 MODIFICATION.AUTHENTICATION OF THIS Indemnification Labor and Materials,Equipment ELECTRONICALLY DRAFTED AIA 317,3.18,9.10.2,10-3.3,10.5,11.4-1.2,11-4-7 1.1-3,1.1.6,3.4,3.5.1,3.8.2,3.8.3,3.12,3.13, DOCUMENT MAY BE MADE BY USING AIA Information and Services Required of the Owner 3.15.1,42.6,4.2.7,5.2.1,6.2.1,7.3.6, 9.3.2,9.3.3, DOCUMENT D401. 2.1.2,2.2,3.2.1,3.12.4,3.12.10,4.2.7,4.3.32 6.1.3, 9.5-1.3,9.10.2,10.2.1,10.2-4,14.2.1.2 6.1.4,6.2-5,9.3.2,9.6.1,9.6-4,9.9.2, 9.10.3, Labor Disputes This document has been approved and endorsed by The Associated General 10.3.3,11.2,U-4,13.5.1,13.5.2,14.1.1.4,14.1.4 8.3.1 Contractors of America. Injury or Damage to Person or Properly Laws and Regulations 4.3.8,10.2,1o.6 1.6,3.2.2,3.6,3.7,3.12.10,3.13,4.1.1,4.4.8,4.6, Inspections 9.6-4,9.9.1,10.2.2,11.1,11.4,13.1, 13.4,13.5.1, 3.1-3,3-3.3,3.7.1,4.2.2,4.2.6,4.2.9,9.4.2,9.8.2, 13.5.2,13.6,14 9.8-3,9.9.2,9.10.1,12.2.1,13.5 Liens Instructions to Bidders 2.1.2,4.4.8,8.2.2,9.3.3,9.10 1.1.1 Limitation on Consolidation or joinder Instructions to the Contractor 4.6.4 3.2.3,3.3.1,3.8.1,4.2.8,5.2.1,7,12,8.2.2,13.5.2 Limitations,Statutes of Insurance 4.6.3,12.2.6,13.7 3.18.1,6.1.1,7.3.6,8.2.1,9.3.2,9.8.4,9.9.1, Limitations of Liability 9.10.2, 9.10.5,11 2.3,3.2.1,3.5.1,3.7.3,3.12.8,3.12.10,3.17,3.18, Insurance,Boiler and Machinery 4.2.6,4.2.7,4.2.12,6.2.2,9.4.2,9.6.4, 9.6.7, 11.4.2 9.10.4,10-3.3,10.2.5,11.1.2,11.2.1,11-4-7,12.2-5, Insurance,Contractor's Liability 13.4.2 11.1 Limitations of Time Insurance,Effective Date of 2.1.2,2.2,2.4,3.2.1,3.7.3,3.10,3.11,3.12.5,3.15.1, 8.2.2,11.1.2 4.2.7,4.3,4.4,4.5,4.6,5.2,5.3, 5.4,6.2.4,7.3, Insurance,Loss of Use 7.4,8.2,9.2,9.3.1,9.3.3,9.4.1,9.52 9.6,9.7,9.8, U-4.3 9.9,9.10,11.1.3,U-4.1-5,11-4.6,U-4-10,12.2,13.5, Insurance,Owner's Liability 13.7,14 112 Loss of Use Insurance Insurance,Project Management Protective 11.4.3 Liability Material Suppliers 11.3 1.6,3.12.1,4.2.4,4.2.6,5.2.1,9.3,9.4.2,9.6, Insurance,Properly 9.10.5 10.2.5,11.4 Materials,Hazardous Insurance,Stored Materials 10.2.4,10.3,10.5 9.3.2,11-4-1-4 Materials,Labor,Equipment and 01997 AIA® 1.1-3,m.6,1.6.1,3.4,3.5.1,3.8.2,3.8.23,3.12,3.13, AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material ,herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 5 3.15.1,4.2.6,4.2.7,5.21,6.2.1, 7.3.6,9.3.2,9.3.3, 2.1.21 2.2,3.2.1,3.12.4,3.12.10,4.2.7,4.3.3,6.1.3, 9.5-1.3,9.10.2,10.2.1,10.2-4,14.2.1.2 6.1.4,6.2.5,9.3.2,9.6.1,9.6.4,9.9.2,9.10.3, Means,Methods,Techniques,Sequences and 10.3.3,11.2,11.4,13.5.1,13.5.2,14.1.1.4,14.1.4 Procedures of Construction Owner's Authority 3.3.1,3.12.10,4.2.2,4.2.7,9.4.2 1.6,2.1.1,2.3,2.4,3.4.2,3.8.1,3.12.10,3.14.2, Mechanic's Lien 4.1.2,4.1.3,4.2.4,4.2.9,4.3.6,4.4.7, 5.2.1,5.2.4, 4.4.8 5.4.1,6.1,6.3,7.2.1,7.3.1,8.2.2,8.3.1,9.3.1,9.3.2, Mediation 9.5-1,9.9-1,9.10.2, 10.3.2,11.1.3,11.3.1,11.4.3, 4.4.1,4.4.5,4.4.6,4.4.8,4.5,4.6.1,4.6.2,8.3.1, 11.4-10,12.2.2;12-3.1,13.2.2,14.3,14.4 10.5 Owner's Financial Capability Minor Changes in the Work 2.2.1,13.2.2,14.1.1.5 1.1.1,3.12.8,4.2.8,4.3.6,7.1,7.4 Owner's Liability Insurance MISCELLANEOUS PROVISIONS 11.2 13 Owner's Loss of Use Insurance Modifications,Definition of 11.4.3 1.1.1 Owner's Relationship with Subcontractors THIS DOCUMENT HAS IMPORTANT LEGAL 1.1.2,5.2,5.3,5.4,9.6.4,9.10.2,14.2.2 CONSEQUENCES.CONSULTATION WITH AN Modifications to the Contract ATTORNEY IS ENCOURAGED WITH 1.1.1,1.1.2,3.7.3,3.11,4.1.2,4.2.1,5.2.3,7,8.3.1, Owner's Right to Carry Out the Work RESPECT TO ITS COMPLETION OR 9-7,10-3.2,11-4-1 2.4,12.2-4-14.2.2.2 MODIFICATION.AUTHENTICATION OF TWS Mutual Responsibility Owner's Right to Clean Up ELECTRONICALLY DRAFTED AIA 6.2 6.3 DOCUMENT MAY BE MADE BY USING AlA Nonconforming Work,Acceptance of Owner's Right to Perform Construction and to DOCUMENT D401. 9.6.6,9.9.3,12.3 Award Separate Contracts 6.1 This document has been approved and Nonconforming Work,Rejection and Correction of Owner's ndorsed b s The Associated General s Right to Stop the Work of America. 2.3,2.4,3.5.1,4.2.6,6.2.5,9.5.1,9.8.2,9.9.3, 2.3 Contractor 9.10.4,12.2.1;13.7-1.3 Owner's Right to Suspend the Work Notice 14.3 2.2.1,2.3,2.4,3.2.3,3.3.1,3.7.2,3.7.4,3.12.9,4.3, Owner's Right to Terminate the Contract 4.4.8,4.6.5,5.2.1,8.2.2,9.7,9.10,10.2.2,11.1.3, 14.2 11.4.62 12.2.2,12.2-4,13.3,13-5.1,13-5.2,14.1,14.2 Ownership and Use of Drawings,Specifications Notice,Written and Other Instruments of Service 2.3,2.4,3.3.1,3.9,3.12.9,3.12.10,4.3,4.4.8, 1.1.1,1.6,2.2.5,3.2.1,3.11.1,3.17.1,4.2.12,5.3 4.6.5,5.2.1,8.2.2,9.7,9.10,10.2.2,10.3, 11.1.3, Partial Occupancy or Use u-4.6,12.2.2,12.2-4,13.3,14 9.6.6,9.9,11-4-1-5 Notice of Testing and Inspections Patching,Cutting and 13.5.1,13.5.2 3.14,6.2.5 Notice to Proceed Patents 8.2.2 3.17 Notices,Permits,Fees and Payment,Applications for 2.2.2,3.7,3.13,7.3.6.4,10.2.2 4.2.5,7.3.8,9.2,9.3,9.4,9.5.1,9.6.3,9.7.1, Observations,Contractor's 9.8-5,9-10.1;9.10.3,9.10.5,11-1.3,14.2.4;14-4.3 1.5.2,3.2,3.7.3,4.3.4 Payment,Certificates for Occupancy 2.2.2,9.6.6,9.8,11.4.1.5 4.2-5,4.2.9,9.3.3,9.4,9.5,9.6.1;9.6.6,9.7.1, Orders,Written 9.10.1,9.10.3,13.7,14.1.1.3,14.2.4 1.1.1,2.3,3.9,4.3.6,7,8.2.2,11.4.9,12.1,12.2, Payment,Failure of � 13.5.2,14.3.1 4.3.6,9.5.1.3, 9.7,9.10.2,14.1.1.3,14.2.1.2,13.6 OWNER Payment,Final 2 4.2.1,4.2.9,4.3.2,9.8.2,9.10,11.1.2,11.1.3,11.4.11 n.4.5,12.3.1,13.7,14.2.4,14.4.3 z, Owner,Definition of Payment Bond,Performance Bond and 2.1 Owner,Information and Services Required of 7.3.6-4,9.6-7,9.10.3,, 11.4.9'11.5 the Payments,Progress 01997 AIA® 4.3-3,9.3,9.6;9.8-5,9.10.3,13.6,14.2.3 AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 9 1958, by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution. WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 6 PAYMENTS AND COMPLETION Resolution of Claims and Disputes 9 4.4,4.5,4.6 Payments to Subcontractors Responsibility for Those Performing the Work 5.4.2,9.5.1.3,9.6.2,9.6-3,9.6-4,9.6-7,11-4.8, 3.3.2,3.18,4.2.3,4.3.8,5.3.1,6.1.3,6.2,6.3,9.5.12 14.2.1.2 10 PCB Retainage 10.3.1 9.3.1,9.6.2,9.8.5,9.9.1,9.10.2,9.10.3 Performance Bond and Payment Bond Review of Contract Documents and Field 7.3.6.4,9.6.7,9.10.3,11.4.9, 11.5 Conditions by Contractor Permits,Fees and Notices 1.5.2,3.22 3.7.3,3.12.7,6.1.3 2.2.25 3.7,313,7.3.6-4,10.2.2 Review of Contractor's Submittals by Owner and PERSONS AND PROPERTY, PROTECTION Architect OF 3.10.1,3.10.2,3.11,3.12,4.2,5.2,6.1-3,9.2,9.8.2 10 Review of Shop Drawings,Product Data and Samples by Contractor Polychlorinated Biphenyl 3.12 THIS DOCUMENT HAS IMPORTANT LEGAL 10.3.1 Rights and Remedies CONSEQUENCES.CONSULTATION WITHAN Product Data,Definition of 1.1.2,2.3,2.4,3.5.1,3.15.2,4.2.6,4.3.4,4.5,4.6, ATTORNEY RESPECT IS ITS COMPLETION WITH R 3.12.2 5.3,5.4,6.1,6.3,7.3.1,8.3,9.5.1,9.7, 10.2.5,10.3, Product Data and Samples,Shop Drawings MODIFICATION.AUTHENTICATION OF THIS P P s 13 g 12.2.2,12.2.4, .4,14 ELECTRONICALLY DRAFTED AIA 3.11,3.12,4.2.7 Royalties,Patents and Copyrights DOCUMENT MAY BE MADE BY USING AIA Progress and Completion 3,17 DOCUMENT D401. 4.2.2,4.3.3,8.2,9.8,9.9.1,14-1.4 Rules and Notices for Arbitration Progress Payments 4.6.2 This document has been approved and 4.3-3,9.3,9.6,9.8-5,9.10.3,13.6,14.2.3 Safety of Persons and Property endorsed by The Associated General Project,Definition of the 10.2,1o.6 Contractors of America. 1.1.4 Safety Precautions and Programs Project Management Protective Liability 3.3.1,4.2.2,4.2-7,5.3.1, 10.1,10.2,1o.6 Insurance Samples,Definition of 11.3 3.12.3 Project Manual,Definition of the Samples,Shop Drawings,Product Data and 1.1.7 3.11,3.12,4.2.7 Project Manuals Samples at the Site,Documents and 2.2.5 3.11 Project Representatives Schedule of Values 4.2.10 Property Insurance 9.2,9'3'1 10.2-5,11.4 Schedules,Construction 1.4-1.2,3-10,3-12.1;3.12.2,4.3-7.2,6.1.3 PROTECTION OF PERSONS AND Separate Contracts and Contractors PROPERTY 1.1.4,3.12.5,3.14.2,4.2.4,4.2.7,4.6.4,6,8.3.1, 10 11.4.7, 12.1.2,12.2.5 Regulations and Laws Shop Drawings,Definition of 1.6,3.2.2,3.6,3.7,3.12.10,3.13,4.1.1,4.4.8,4.6, 3.12.1 9.6-4.9-9.1,10.2.2,11-1,11-4,13-1, 13.4,13.5.1, Shop Drawings,Product Data and Samples 13-5.2,13.6,14 3.11,3.12,4.2.7 Rejection of Work Site,Use of 3-5-1,4.2.6,12.2.1 - Releases and Waivers of Liens Inspections 6.2.1 Site Inspections 9.10.2 1.2.2,3.2.1,3.33,3.7.1,4.22 4.3.4,9.4.2,9.10.1, Representations 13.5 , 1.5.2,3.5.1,3.12.6,6.2.2,8.2.1,9.33,9.4.2,9.5.1, Site Visits,Architect's 9.8.2,9.10.1 4.2.2,4.2.9,43.4,9.4.2,9.5.1,9.9.2,9.10.1,13.5 �r■� Representatives Special Inspections and Testing 2.1.1,3.1.1,3.9,4.1.1,4.2.1,4.2.10,5.1.1,5.1.2, 4.2.6,12.2.1,13-5 01997 AIA® 13.2.1 Specifications,Definition of the AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1966, 1967, 1970, 1976, 1987, 0 1997 The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 7 111111110 0 1.1.6 5.4.2,14.3 Specifications,The Suspension or Termination of the Contract 1.1.1, 1.1.6,1.1.7,1.2.2,1.6,3.11,3.12.10,3.17 4.3.6,5.4-1.1,11-4.9,14 Statute of Limitations Taxes 4.6.3,12.2.6,13.7 3.6,3.8.2.1,7.3.6.4 Stopping the Work Termination by the Contractor 2.3,4.3.6,9.7,10.3,14.1 4.3-10,14.1 Stored Materials Termination by the Owner for Cause 6.2.1,9-3.2,10.2.1.2,10.2-4,11.4.1.4 4-3-10,5-4-1-1, 14.2 Subcontractor,Definition of Termination of the Architect 5.1.1 4.1.3 SUBCONTRACTORS Termination of the Contractor 5 14.2.2 Subcontractors,Work by TERMINATION OR SUSPENSION OF THE 1.2.2,3.3.2,3.12.1,4.2.3,5.2.3,5.3,5.4,9.3.1.2, CONTRACT THIS DOCUMENT HAS IMPORTANT LEGAL 9.6.7 14 CONSEQUENCES.CONSULTATION WITHAN Subcontractual Relations Tests and Inspections ATTORNEY 15 ENCOURAGED WITH 5.3,5.4,9.3.1.2,9.6,9.1010.2.1,11.4.7,11.4.8, RESPECT TO ITS COMPLETION OR 3.1.3,3.3.3,4.2.2,4.2.6,4.2.9,9.4.2,9.8.3,9.9.2, 14.1,14.2.1,14.3.2 9.10.1,10.3.2,11.4.1.1,12.2.1,13.5 MODIFICATION.AUTHENTICATION OF THIS Submittals TIME ELECTRONICALLY DRAFTED AIA 1.6,3.10,3.11,3.12,4.2-7,5.2.1,5.2-3,7.3.6,9.2, DOCUMENT MAY BE MADE BY USING AIA 9.3,9.8,9.9.1,9.10.2,9.10.3,H-1.3 8 DOCUMENT M1. Subrogation,Waivers of Time,Delays and Extensions of 6.1.1,11.4.5, 11.4.7 3.2.3,4.3.1,4.3.4,4.3.7,4.4.5,5.2.3,7.2.1,7.3.1, This document has been approved and Substantial Completion 7-4-1,7.5.1,8.3,9.5-1,9.7-1,10-3.2, 1o.6.1,14.3.2 endorsed by The Associated General 4.2.9,8.1.1,8.1.3,8.2.3,9.4.2,9.8,9.9.1,9.10.3, Time Limits Contractors of America. 9.10-4.2,12.2,13-7 2.1.2,2.2,2.4,3.2.1,3.7.3,3.10,3.11,3.12.5,3.15.1, Substantial Completion,Definition of 4.2,4-3,4-4,4-5,4-6,5-2,5-3,5-4, 6.2-4,7.3, 9.8.1 7.4,8.2,9.2,9.3.1,9.3.3,9.4.1,9.5,9.6,9.7,9.8, Substitution of Subcontractors 9.9,9.10,11.1.3,11.4-1.5, 11.4.6,11.4.10,12.2,13.5, 5.2.3,5.2.4 13.7,14 Substitution of Architect Time Limits on Claims 4.1.3 4.3.2,4.3.4,4.3.8,4.4,4.5,4.6 Substitutions of Materials Title to Work 3.4.2,3.5.1,7.3.7 9.3.2,9.3.3 Sub-subcontractor,Definition of UNCOVERING AND CORRECTION OF 5.1.2 WORK Subsurface Conditions 12 4.3.4 Uncovering of Work Successors and Assigns 12.1 13.2 Unforeseen Conditions Superintendent 4.3-4,8.3.1,10.3 3.9,10.2.6 Unit Prices Supervision and Construction Procedures 4-3-9,7-3-3.2 1.2.2,3.3, 3-4,3.12.10,4.2.2,4.2-7,4.3.3,6.1.3, Use of Documents 6.2-4,7.1.3.7.3.6,8.2,8.3.1,9.4.2,10, 12,14 1.1.1,1.6,2.2-5,3-12.6,5.3 Surety Use of Site 4.4.7,5-4-1.2,9.8-5,9.10.2,9.10.3,14.2.2 3.13,6.1.1,6.2.1 Surety,Consent of Values,Schedule of 9.10.2,9.10.3 9.2,9.3.1 ' Surveys Waiver of Claims by the Architect 2.2.3 13.4.2 Suspension by the Owner for Convenience Waiver of Claims by the Contractor 14.4 4.3-10,9.10.5,11-4.7,13-4.2 01997 AIA® Suspension of the Work AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 9 y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: I's 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 8 1111110 %# Waiver of Claims by the Owner Written Consent 4.3-10,9.9.3,9-10.3,9-10-4,11-4.3,11-4.5,11-4.7, 1.6,3.4.2,3.12.8,3.14.2,4.1.2,4.3.4,4.6.4,9.3.2, 12.2.2.1,13-4.2,14.2.4 9.8.5,9.9.1,9.10.2,9.10.3,11.4-12 13.2213-4.2 Waiver of Consequential Damages Written Interpretations 4.3.10,14.2.4 4.2.11,4.2.12,4.3.6 Waiver of Liens Written Notice 9.10.2,9.10.4 2.3,2.4,3.3.1,3.9,3.12.9,3.12.10,4.3,4.4.8, Waivers of Subrogation 4.6.5,5.2.1,8.2.2,9.7,9.10,10.2.2,10.3, 11.1.3, 6.1.1,11-4.5,11.4.7 11-4.6,12.2.2,12.2-4, 13.3,14 Warranty Written Orders 3.5,4.2.9,4.3.5.3,9.3.3,9.8.4,9.9.1,9.10.4, 1.1.1,2.3,3.9,4.3.6,7,8.2.2,11.4.9,12.1,12.2, 12.2.2,13.7-1.3 13.5.2,14.3.1 Weather Delays 4.3.7.2 Work,Definition of THIS DOCUMENT HAS IMPORTANT LEGAL 1.1.3 CONSEQUENCES.CONSULTATION WITH AN ATTORNEY 15 ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF THIS ARTICLE 1 GENERAL PROVISIONS ELECTRONICALLY DRAFTED AIA 1.1 BASIC DEFINITIONS DOCUMENT MAY BE MADE BY USING AIA 1.1.1 THE CONTRACT DOCUMENTS DOCUMENTMI. The Contract Documents consist of the Agreement between Owner and Contractor (hereinafter the Agreement), Conditions of the Contract (General, Supplementary and other This document has been approved and Conditions), Drawings, Specifications, Addenda issued prior to execution of the Contract, endorsed by The Associated General other documents listed in the Agreement and Modifications issued after execution of the Contractors of America. Contract.A Modification is(1)a written amendment to the Contract signed by both parties,(2) a Change Order,(3)a Construction Change Directive or(4)a written order for a minor change in the Work issued by the Architect. Unless specifically enumerated in the Agreement, the Contract Documents do not include other documents such as bidding requirements (advertisement or invitation to bid,Instructions to Bidders,sample forms,the Contractor's bid or portions of Addenda relating to bidding requirements). 1.1.2 THE CONTRACT The Contract Documents form the Contract for Construction. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. The Contract may be amended or modified only by a Modification. The Contract Documents shall not be construed to create a contractual relationship of any kind(1) between the Architect and Contractor,(2)between the Owner and a Subcontractor or Sub-subcontractor, (3)between the Owner and Architect or(4) between any persons or entities other than the Owner and Contractor. The Architect shall, however, be entitled to performance and enforcement of obligations under the Contract intended to facilitate performance of the Architect's duties. 1.1.3 THE WORK The term "Work" means the construction and services required by the Contract Documents, whether completed or partially completed, and includes all other labor,materials, equipment !� and services provided or to be provided by the Contractor to fulfill the Contractors obligations. The Work may constitute the whole or a part of the Project. 1.1.4 THE PROJECT f . � The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part and which may include construction by the Owner or by separate contractors. 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1951, 1958, 9 6 , 1970, 1976, 1987, Q 1997 by e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 9 1.1.5 THE DRAWINGS The Drawings are the graphic and pictorial portions of the Contract Documents showing the design, location and dimensions of the Work, generally including plans, elevations, sections, details,schedules and diagrams. 1.1.6 THE SPECIFICATIONS The Specifications are that portion of the Contract Documents consisting of the written requirements for materials,equipment,systems,standards and workmanship for the Work,and performance of related services. 1.1.7 THE PROJECT MANUAL The Project Manual is a volume assembled for the Work which may include the bidding requirements,sample forms,Conditions of the Contract and Specifications. 1.2 CORRELATION AND INTENT OF THE CONTRACT DOCUMENTS THIS DOCUMENT HAS IMPORTANT LEGAL 1.2.1 The intent of the Contract Documents is to include all items necessary for the proper CONSEQUENCES.CONSULTATION WITHAN execution and completion of the Work by the Contractor. The Contract Documents are ATTORNEY IS ENCOURAGED WITH complementary, and what is required by one shall be as binding as if required by all; RESPECT TO ITS COMPLETION OR performance by the Contractor shall be required only to the extent consistent with the Contract MODIFICATION.AUTHENTICATION OF THIS Documents and reasonably inferable from them as being necessary to produce the indicated ELECTRONICALLY DRAFTED AIA results. DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. 1.2.2 Organization of the Specifications into divisions, sections and articles, and arrangement of Drawings shall not control the Contractor in dividing the Work among This document has been approved and endorsed by The Associated General Subcontractors or in establishing the extent of Work to be performed by any trade. Contractors of America. 1.2.3 Unless otherwise stated in the Contract Documents, words which have well-known technical or construction industry meanings are used in the Contract Documents in accordance with such recognized meanings. 1.3 CAPITALIZATION 1.3.1 Terms capitalized in these General Conditions include those which are (i)specifically defined, (2) the titles of numbered articles and identified references to Paragraphs, Subparagraphs and Clauses in the document or(3) the titles of other documents published by the American Institute of Architects. 1.4 INTERPRETATION 1.4.1 In the interest of brevity the Contract Documents frequently omit modifying words such as "all" and "any" and articles such as "the" and "an," but the fact that a modifier or an article is absent from one statement and appears in another is not intended to affect the interpretation of either statement. 1.5 EXECUTION OF CONTRACT DOCUMENTS 1.5.1 The Contract Documents shall be signed by the Owner and Contractor. If either the Owner or Contractor or both do not sign all the Contract Documents, the Architect shall identify such unsigned Documents upon request. 1.5.2 Execution of the Contract by the Contractor is a representation that the Contractor has visited the site,become generally familiar with local conditions under which the Work is to ,,+, , be performed and correlated personal observations with requirements of the Contract f D ov ocuments. .1 1.6 OWNERSHIP AND USE OF DRAWINGS, SPECIFICATIONS AND OTHER 01997 AIA® INSTRUMENTS OF SERVICE AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 5, , 1958, y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 10 1.6.1 The Drawings, Specifications and other documents, including those in electronic form, prepared by the Architect and the Architect's consultants are Instruments of Service through which the Work to be executed by the Contractor is described. The Contractor may retain one record set. Neither the Contractor nor any Subcontractor, Sub-subcontractor or material or equipment supplier shall own or claim a copyright in the Drawings, Specifications and other documents prepared by the Architect or the Architect's consultants, and unless otherwise indicated the Architect and the Architect's consultants shall be deemed the authors of them and will retain all common law, statutory and other reserved rights, in addition to the copyrights. All copies of Instruments of Service, except the Contractor's record set, shall be returned or suitably accounted for to the Architect,on request,upon completion of the Work. The Drawings, Specifications and other documents prepared by the Architect and the Architect's consultants,and copies thereof furnished to the Contractor,are for use solely with respect to this Project. They are not to be used by the Contractor or any Subcontractor, Sub- subcontractor or material or equipment supplier on other projects or for additions to this Project outside the scope of the Work without the specific written consent of the Owner, Architect and the Architect's consultants.The Contractor, Subcontractors, Sub-subcontractors THIS DOCUMENT HAS IMPORTANT LEGAL and material or equipment suppliers are authorized to use and reproduce applicable portions of CONSEQUENCES.CONSULTATION WITH AN the Drawings, Specifications and other documents prepared by the Architect and the ATTORNEY IS ENCOURAGED WITH Architect's consultants appropriate to and for use in the execution of their Work under the RESPECT TO ITS COMPLETION OR Contract Documents. All copies made under this authorization shall bear the statutory MODIFICATION.AUTHENTICATION OF THIS copyright notice,if any,shown on the Drawings,Specifications and other documents prepared ELECTRONICALLY DRAFTED AIA by the Architect and the Architect's consultants. Submittal or distribution to meet official DOCUMENT MAY BE MADE BY USING AIA regulatory requirements or for other purposes in connection with this Project is not to be DOCUMENT D401. construed as publication in derogation of the Architect's or Architect's consultants'copyrights This document has been approved and or other reserved rights. endorsed by The Associated General ARTICLE 2 OWNER Contractors of America. 2.1 GENERAL 2.1.1 The Owner is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number.The Owner shall designate in writing a representative who shall have express authority to bind the Owner with respect to all matters requiring the Owner's approval or authorization. Except as otherwise provided in Subparagraph 4.2.1,the Architect does not have such authority. The term "Owner" means the Owner or the Owner's authorized representative. 2.1.2 The Owner shall furnish to the Contractor within fifteen days after receipt of a written request, information necessary and relevant for the Contractor to evaluate,give notice of or enforce mechanic's lien rights. Such information shall include a correct statement of the record legal title to the property on which the Project is located,usually referred to as the site, and the Owner's interest therein. 2.2 INFORMATION AND SERVICES REQUIRED OF THE OWNER 2.2.1 The Owner shall,at the written request of the Contractor,prior to commencement of the Work and thereafter, furnish to the Contractor reasonable evidence that financial arrangements have been made to fulfill the Owner's obligations under the Contract.Furnishing of such evidence shall be a condition precedent to commencement or continuation of the Work. After such evidence has been furnished, the Owner shall not materially vary such financial arrangements without prior notice to the Contractor. 2.2.2 Except for permits and fees,including those required under Subparagraph 3.7.1,which are the responsibility of the Contractor under the Contract Documents,the Owner shall secure f . and pay for necessary approvals,easements,assessments and charges required for construction, r� use or occupancy of permanent structures or for permanent changes in existing facilities. 01997 AIAO AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE s opyng t 1925, 1937, 1951, 9 1970, 1976, 1987, Q 1997 by e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 11 2.2.3 The Owner shall furnish surveys describing physical characteristics, legal limitations and utility locations for the site of the Project, and a legal description of the site. The Contractor shall be entitled to rely on the accuracy of information furnished by the Owner but shall exercise proper precautions relating to the safe performance of the Work. 2.2.4 Information or services required of the Owner by the Contract Documents shall be furnished by the Owner with reasonable promptness. Any other information or services relevant to the Contractor's performance of the Work under the Owner's control shall be furnished by the Owner after receipt from the Contractor of a written request for such information or services. 2.2.5 Unless otherwise provided in the Contract Documents, the Contractor will be furnished, free of charge, such copies of Drawings and Project Manuals as are reasonably necessary for execution of the Work. THIS DOCUMENT HAS IMPORTANT LEGAL 2.3 OWNER'S RIGHT TO STOP THE WORK CONSEQUENCES.CONSULTATION WITH AN 2.3.1 If the Contractor fails to correct Work which is not in accordance with the ATTORNEY 15 ENCOURAGED WITH requirements of the Contract Documents as required by Paragraph 12.2 or persistently fails to RESPECT TO ITS COMPLETION OR carry out Work in accordance with the Contract Documents, the Owner may issue a written MODIFICATION.AUTHENTICATION OF THIS order to the Contractor to stop the Work,or any portion thereof,until the cause for such order ELECTRONICALLY DRAFTED AIA has been eliminated;however,the right of the Owner to stop the Work shall not give rise to a DOCUMENT MAY BE MADE BY USING AIA duty on the part of the Owner to exercise this right for the benefit of the Contractor or any DOCUMENT D401. other person or entity,except to the extent required by Subparagraph 6.1.3. This document has been approved and 2.4 OWNER'S RIGHT TO CARRY OUT THE WORK endorsed by The Associated General 2.4.1 If the Contractor defaults or neglects to carry out the Work in accordance with the Contractors of America. Contract Documents and fails within a seven-day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness,the Owner may after such seven-day period give the Contractor a second written notice to correct such deficiencies within a three-day period. If the Contractor within such three-day period after receipt of such second notice fails to commence and continue to correct any deficiencies, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner's.expenses and compensation for the Architect's additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner. ARTICLE 3 CONTRACTOR 3.1 GENERAL 3.1.1 The Contractor is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "Contractor"means the Contractor or the Contractors authorized representative. 3.1.2 The Contractor shall perform the Work in accordance with the Contract Documents. 3.1.3 The Contractor shall not be relieved of obligations to perform the Work in accordance with the Contract Documents either by activities or duties of the Architect in the Architect's ,� administration of the Contract,or by tests,inspections or approvals required or performed by �f++Ir� ' persons other than the Contractor. 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 12 Q (a 3.2 REVIEW OF CONTRACT DOCUMENTS. AND FIELD CONDITIONS BY CONTRACTOR 3.2.1 Since the Contract Documents are complementary,before starting each portion of the Work, the Contractor shall carefully study and compare the various Drawings and other Contract Documents relative to that portion of the Work,as well as the information furnished by the Owner pursuant to Subparagraph 2.2.3, shall take field measurements of any existing conditions related to that portion of the Work and shall observe any conditions at the site affecting it.These obligations are for the purpose of facilitating construction by the Contractor and are not for the purpose of discovering errors,omissions,or inconsistencies in the Contract Documents; however, any errors, inconsistencies or omissions discovered by the Contractor shall be reported promptly to the Architect as a request for information in such form as the Architect may require. 3.2.2 Any design errors or omissions noted by the Contractor during this review shall be reported promptly to the Architect,but it is recognized that the Contractor's review is made in THIS DOCUMENT HAS IMPORTANT LEGAL the Contractor's capacity as a contractor and not as a licensed design professional unless CONSEQUENCES.CONSULTATION WITHAN otherwise specifically provided in the Contract Documents. The Contractor is not required to ATTORNEY 15 ENCOURAGED WITH ascertain that the Contract Documents are in accordance with applicable laws, statutes, RESPECT TO ITS COMPLETION OR ordinances,building codes,and rules and regulations,but any nonconformity discovered by or MODIFICATION.AUTHENTICATION OF THIS made known to the Contractor shall be reported promptly to the Architect. ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA 3.2.3 If the Contractor believes that additional cost or time is involved because of DOCUMENT D401. clarifications or instructions issued by the Architect in response to the Contractors notices or requests for information pursuant to Subparagraphs 3.2d and 3.2.2,the Contractor shall make This document has been approved and Claims as provided in Subparagraphs 4.3.6 and 4.3.7. If the Contractor fails to perform the endorsed by The Associated General obligations of Subparagraphs 3.21 and 3.2.2,the Contractor shall pay such costs and damages to Contractors of America. the Owner as would have been avoided if the Contractor had performed such obligations.The Contractor shall not be liable to the Owner or Architect for damages resulting from errors, inconsistencies or omissions in the Contract Documents or for differences between field measurements or conditions and the Contract Documents unless the Contractor recognized such error, inconsistency, omission or difference and knowingly failed to report it to the Architect. 3.3 SUPERVISION AND CONSTRUCTION PROCEDURES 3.3.1 The Contractor shall supervise and direct the Work,using the Contractor's best skill and attention.The Contractor shall be solely responsible for and have control over construction means,methods,techniques,sequences and procedures and for coordinating all portions of the Work under the Contract, unless the Contract Documents give other specific instructions concerning these matters. If the Contract Documents give specific instructions concerning construction means, methods, techniques, sequences or procedures, the Contractor shall evaluate the jobsite safety thereof and, except as stated below, shall be fully and solely responsible for the jobsite safety of such means,methods,techniques,sequences or procedures. If the Contractor determines that such means, methods,techniques,sequences or procedures may not be safe,the Contractor shall give timely written notice to the Owner and Architect and shall not proceed with that portion of the Work without further written instructions from the Architect. If the Contractor is then instructed to proceed with the required means, methods, techniques, sequences or procedures without acceptance of changes proposed by the Contractor,the Owner shall be solely responsible for any resulting loss or damage. 3.3.2 The Contractor shall be responsible to the Owner for acts and omissions of the �, , Contractor's employees, Subcontractors and their agents and employees,and other persons or entities performing portions of the Work for or on behalf of the Contractor or any of its �■� Subcontractors. 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE >, opyng t 1951, 9 by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia — 1213/2002. AIA License Number 1008538, which expires on 9/3/2003. 13 3.3.3 The Contractor shall be responsible for inspection of portions of Work already performed to determine that such portions are in proper condition to receive subsequent Work. 3.4 LABOR AND MATERIALS 3.4.1 Unless otherwise provided in the Contract Documents, the Contractor shall provide and pay for labor,materials,equipment,tools,construction equipment and machinery,water, heat, utilities, transportation, and other facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. 3.4.2 The Contractor may make substitutions only with the consent of the Owner, after evaluation by the Architect and in accordance with a Change Order. 3.4.3 The Contractor shall enforce strict discipline and good order among the Contractor's employees and other persons carrying out the Contract. The Contractor shall not permit THIS DOCUMENT HAS IMPORTANT LEGAL employment of unfit persons or persons not skilled in tasks assigned to them. CONSEQUENCES.CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH 3.5 WARRANTY RESPECT TO ITS COMPLETION OR 3.5.1 The Contractor warrants to the Owner and Architect that materials and equipment•MODIFICATION.AUTHENTICATION OF THIS furnished under the Contract will be of good quality and new unless otherwise required or ELECTRONICALLY DRAFTED AIA permitted by the Contract Documents,that the Work will be free from defects not inherent in DOCUMENT MAY BE MADE BY USING AIA the quality required or permitted, and that the Work will conform to the requirements of the DOCUMENT D401. Contract Documents.Work not conforming to these requirements,including substitutions not This document has been approved and properly approved and authorized, may be considered defective. The Contractor's warranty endorsed by The Associated General excludes remedy for damage or defect caused by abuse, modifications not executed by the Contractors of America. Contractor, improper or insufficient maintenance, improper operation, or normal wear and tear and normal usage. If required by the Architect, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. 3.6 TAXES 3.6.1 The Contractor shall pay sales,consumer,use and similar taxes for the Work provided by the Contractor which are legally enacted when bids are received or negotiations concluded, whether or not yet effective or merely scheduled to go into effect. 3.7 PERMITS, FEES AND NOTICES 3.7.1 Unless otherwise provided in the Contract Documents, the Contractor shall secure and pay for the building permit and other permits and governmental fees, licenses and inspections necessary for proper execution and completion of the Work which are customarily secured after execution of the Contract and which are legally required when bids are received or negotiations concluded. 3.7.2 The Contractor shall comply with and give notices required by laws,ordinances,rules, regulations and lawful orders of public authorities applicable to performance of the Work 3.7.3 It is not the Contractor's responsibility to ascertain that the Contract Documents are in accordance with applicable laws, statutes, ordinances, building codes, and rules and �• regulations. However,if the Contractor observes that portions of the Contract Documents are at variance therewith,the Contractor shall promptly notify the Architect and Owner in writing, and necessary changes shall be accomplished by appropriate Modification. 3.7.4 If the Contractor performs Work knowing it to be contrary to laws, statutes, ordinances,building codes,and rules and regulations without such notice to the Architect and Owner,the Contractor shall assume appropriate responsibility for such Work and shall bear the 01997 AIA® costs attributable to correction. AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 14 APN 3.8 ALLOWANCES 3.8.1 The Contractor shall include in the Contract Sum all allowances stated in the Contract Documents. Items covered by allowances shall be supplied for such amounts and by such persons or entities as the Owner may direct, but the Contractor shall not be required to employ persons or entities to whom the Contractor has reasonable objection. 3.8.2 Unless otherwise provided in the Contract Documents: 1 allowances shall cover the cost to the Contractor of materials and equipment delivered at the site and all required taxes,less applicable trade discounts; .2 Contractor's costs for unloading and handling at the site,labor,installation costs, overhead, profit and other expenses contemplated for stated allowance amounts shall be included in the Contract Sum but not in the allowances; .3 whenever costs are more than or less than allowances,the Contract Sum shall be THIS DOCUMENT HAS IMPORTANT LEGAL adjusted accordingly by Change Order. The amount of the Change Order shall CONSEQUENCES.CONSULTATION WITH AN reflect (1) the difference between actual costs and the allowances under Clause ATTORNEY IS ENCOURAGED WITH 3.8.2.1 and(2)changes in Contractor's costs under Clause 3.8.2.2. RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF THMS 3.8.3 Materials and equipment under an allowance shall be selected by the Owner in ELECTRONICALLY DRAFTED AIA sufficient time to avoid delay in the Work. DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. 3.9 SUPERINTENDENT This document has been approved and 3.9.1 The Contractor shall employ a competent superintendent and necessary assistants endorsed by The Associated General who shall be in attendance at the Project site during performance of the Work. The Contractors of America. superintendent shall represent the Contractor, and communications given to the superintendent shall be as binding as if given to the Contractor. Important communications shall be confirmed in writing. Other communications shall be similarly confirmed on written request in each case. 3.10 CONTRACTOR'S CONSTRUCTION SCHEDULES 3.10.1 The Contractor,promptly after being awarded the Contract,shall prepare and submit for the Owner's and Architect's information a Contractor's construction schedule for the Work. The schedule shall not exceed time limits current under the Contract Documents, shall be revised at appropriate intervals as required by the conditions of the Work and Project,shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work. 3.10.2 The Contractor shall prepare and keep current, for the Architect's approval, a schedule of submittals which is coordinated with the Contractor's construction schedule and allows the Architect reasonable time to review submittals. 3.10.3 The Contractor shall perform the Work in general accordance with the most recent schedules submitted to the Owner and Architect. 3.11 DOCUMENTS AND SAMPLES AT THE SITE 3.11.1 The Contractor shall maintain at the site for the Owner one record copy of the Drawings,Specifications,Addenda,Change Orders and other Modifications,in good order and marked currently to record field changes and selections made during construction, and one +, record copy of approved Shop Drawings, Product Data, Samples and similar required submittals. These shall be available to the Architect and shall be delivered to the Architect for r submittal to the Owner upon completion of the Work. 01997 AIA® 3.12 SHOP DRAWINGS, PRODUCT DATA AND SAMPLES AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 5 9 y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material ,herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 15 3.12.1 Shop Drawings are drawings, diagrams, schedules and other data specially prepared for the Work by the Contractor or a Subcontractor,Sub-subcontractor,manufacturer,supplier or distributor to illustrate some portion of the Work. 3.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures,diagrams and other information furnished by the Contractor to illustrate materials or equipment for some portion of the Work. 3.12.3 Samples are physical examples which illustrate materials,equipment or workmanship and establish standards by which the Work will be judged. 3.12.4 Shop Drawings, Product Data, Samples and similar submittals are not Contract Documents. The purpose of their submittal is to demonstrate for those portions of the Work for which submittals are required by the Contract Documents the way by which the Contractor proposes to conform to the information given and the design concept expressed in the THIS DOCUMENT HAS IMPORTANT LEGAL Contract Documents. Review by the Architect is subject to the limitations of Subparagraph CONSEQUENCES.CONSULTATION WITHAN 4.2.7. Informational submittals upon which the Architect is not expected to take responsive ATTORNEY 15 ENCOURAGED WITH action may be so identified in the Contract Documents. Submittals which are not required by RESPECT TO ITS COMPLETION OR the Contract Documents may be returned by the Architect without action. MODIFICATION.AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA 3.12.5 The Contractor shall review for compliance with the Contract Documents, approve DOCUMENT MAY BE MADE BY USING AIA and submit to the Architect Shop Drawings, Product Data, Samples and similar submittals DOCUMENT MI. required by the Contract Documents with reasonable promptness and in such sequence as to cause no delay in the Work or in the activities of the Owner or of separate contractors. This document has been approved and Submittals which are not marked as reviewed for compliance with the Contract Documents endorsed by The Associated General and approved by the Contractor may be returned by the Architect without action. Contractors of America. 3.12.6 By approving and submitting Shop Drawings, Product Data, Samples and similar submittals, the Contractor represents that the Contractor has determined and verified materials, field measurements and field construction criteria related thereto,or will do so,and has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 3.12.7 The Contractor shall perform no portion of the Work for which the Contract Documents require submittal and review of Shop Drawings,Product Data,Samples or similar submittals until the respective submittal has been approved by the Architect. 3.12.8 The Work shall be in accordance with approved submittals except that the Contractor shall not be relieved of responsibility for deviations from requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data, Samples or similar submittals unless the Contractor has specifically informed the Architect in writing of such deviation at the time of submittal and (1) the Architect has given written approval to the specific deviation as a minor change in the Work, or (2) a Change Order or Construction Change Directive has been issued authorizing the deviation. The Contractor shall not be relieved of responsibility for errors or omissions in Shop Drawings, Product Data, Samples or similar submittals by the Architect's approval thereof. 3.12.9 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings,Product Data,Samples or similar submittals,to revisions other than those requested by the Architect on previous submittals. In the absence of such written notice the Architect's approval of a resubmission shall not apply to such revisions. ; , art 3.12.10 The Contractor shall not be required to provide professional services which constitute the practice of architecture or engineering unless such services are specifically required by the 01997 AIA® Contract Documents for a portion of the Work or unless the Contractor needs to provide such AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 16 services in order to carry out the Contractor's responsibilities for construction means,methods, techniques, sequences and procedures. The Contractor shall not be required to provide professional services in violation of applicable law. If professional design services or certifications by a design professional related to systems,materials or equipment are specifically required of the Contractor by the Contract Documents, the Owner and the Architect will specify all performance and design criteria that such services must satisfy.The Contractor shall cause such services or certifications to be provided by a properly licensed design professional, whose signature and seal shall appear on all drawings,calculations,specifications,certifications, Shop Drawings and other submittals prepared by such professional. Shop Drawings and other submittals related to the Work designed or certified by such professional,if prepared by others, shall bear such professional's written approval when submitted to the Architect. The Owner and the Architect shall be entitled to rely upon the adequacy,accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided the Owner and Architect have specified to the Contractor all performance and design criteria that such services must satisfy. Pursuant to this Subparagraph 3.12.10, the Architect will review, approve or take other appropriate action on submittals only for the limited purpose of checking THIS DOCUMENT HAS IMPORTANT LEGAL for conformance with information given and the design concept expressed in the Contract CONSEOUENCES.CONSULTATION WITHAN Documents. The Contractor shall not be responsible for the adequacy of the performance or ATTORNEY 15 ENCOURAGED WITH design criteria required by the Contract Documents. RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF TENS 3.13 USE OF SITE ELECTRONICALLY DRAFTED AIA 3.13.1 The Contractor shall confine operations at the site to areas permitted by law, DOCUMENT MAY BE MADE BY USING AIA ordinances,permits and the Contract Documents and shall not unreasonably encumber the site DOCUMENT D401. with materials or equipment. This document has been approved and endorsed by The Associated General 3.14 CUTTING AND PATCHING Contractors of America. 3.14.1 The Contractor shall be responsible for cutting, fitting or patching required to complete the Work or to make its parts fit together properly. 3.14.2 The Contractor shall not damage or endanger a portion of the Work or fully or partially completed construction of the Owner or separate contractors by cutting,patching or otherwise altering such construction, or by excavation. The Contractor shall not cut or otherwise alter such construction by the Owner or a separate contractor except with written consent of the Owner and of such separate contractor,such consent shall not be unreasonably withheld. The Contractor shall not unreasonably withhold from the Owner or a separate contractor the Contractor's consent to cutting or otherwise altering the Work. 3.15 CLEANING UP 3.15.1 The Contractor shall keep the premises and surrounding area free from accumulation of waste materials or rubbish caused by operations under the Contract. At completion of the Work, the Contractor shall remove from and about the Project waste materials, rubbish, the Contractor's tools,construction equipment,machinery and surplus materials. 3.15.2 If the Contractor fails to clean up as provided in the Contract Documents,the Owner may do so and the cost thereof shall be charged to the Contractor. 3.16 ACCESS TO WORK '= 3.16.1 The Contractor shall provide the Owner and Architect access to the Work in preparation and progress wherever located. gli I .+ 3.17 ROYALTIES, PATENTS AND COPYRIGHTS 'a�+�it•:r'r 3.17.1 The Contractor shall pay all royalties and license fees. The Contractor shall defend suits or claims for infringement of copyrights and patent rights and shall hold the Owner and Architect harmless from loss on account thereof,but shall not be responsible for such defense 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE opyng t 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 8 , Q 1997 by T e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia — 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 17 or loss when a particular design, process or product of a particular manufacturer or manufacturers is required by the Contract Documents or where the copyright violations are contained in Drawings,Specifications or other documents prepared by the Owner or Architect. However,if the Contractor has reason to believe that the required design,process or product is an infringement of a copyright or a patent, the Contractor shall be responsible for such loss unless such information is promptly furnished to the Architect. 3.18 INDEMNIFICATION 3.18.1 To the fullest extent permitted by law and to the extent claims, damages, losses or expenses are not covered by Project Management Protective Liability insurance purchased by the Contractor in accordance with Paragraph 11.3, the Contractor shall indemnify and hold harmless the Owner, Architect, Architect's consultants, and agents and employees of any of them from and against claims, damages, losses and expenses, including but not limited to attorneys' fees, arising out of or resulting from performance of the Work, provided that such claim,damage,loss or expense is attributable to bodily injury,sickness,disease or death,or to injury to or destruction of tangible property(other than the Work itself),but only to the extent THIS DOCUMENT HAS IMPORTANT LEGAL caused by the negligent acts or omissions of the Contractor,a Subcontractor,anyone directly or CONSEQUENCES.CONSULTATION WITHAN indirectly employed by them or anyone for whose acts they may be liable,regardless of whether ATTORNEY IS ENCOURAGED WITH or not such claim,damage,loss or expense is caused in part by a party indemnified hereunder. RESPECT TO ITS COMPLETION OR Such obligation shall not be construed to negate,abridge,or reduce other rights or obligations MODTRONIFICATION. LLY AUTHENTICATIO AIA N OF THIS of indemnity which would otherwise exist as to a party or person described in this Paragraph DOCUMENT MAY BE MADE BY USING AIA 3.18. DOCUMENT D401. 3.18.2 In claims against any person or entity indemnified under this Paragraph 3.18 by an This document has been approved and employee of the Contractor, a Subcontractor,anyone directly or indirectly employed by them endorsed by The Associated General or anyone for whose acts they may be liable, the indemnification obligation under Contractors of America. Subparagraph 3.18.1 shall not be limited by a limitation on amount or type of damages, compensation or benefits payable by or for the Contractor or a Subcontractor under workers' compensation acts,disability benefit acts or other employee benefit acts. ARTICLE 4 ADMINISTRATION OF THE CONTRACT 4.1 ARCHITECT 4.1.1 The Architect is the person lawfully licensed to practice architecture or an entity lawfully practicing architecture identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number.The term"Architect"means the Architect or the Architect's authorized representative. 4.1.2 Duties,responsibilities and limitations of authority of the Architect as set forth in the Contract Documents shall not be restricted, modified or extended without written consent of the Owner,Contractor and Architect.Consent shall not be unreasonably withheld. 4.1.3 If the employment of the Architect is terminated, the Owner shall employ a new Architect against whom the Contractor has no reasonable objection and whose status under the Contract Documents shall be that of the former Architect. 4.2 ARCHITECT'S ADMINISTRATION OF THE CONTRACT 4.2.1 The Architect will provide administration of the Contract as described in the Contract Documents, and will be an Owner's representative (1) during construction, (2) until final payment is due and(3)with the Owner's concurrence,from time to time during the one-year period for correction of Work described in Paragraph 12.2.The Architect will have authority to ,'!' , act on behalf of the Owner only to the extent provided in the Contract Documents, unless otherwise modified in writing in accordance with other provisions of the Contract. �r 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 9 by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 121312002. AIA License Number 1008538, which expires on 9/3/2003. 18 4.2.2 The Architect, as a representative of the Owner, will visit the site at intervals appropriate to the stage of the Contractor's operations (i) to become generally familiar with and to keep the Owner informed about the progress and quality of the portion of the Work completed, (2) to endeavor to guard the Owner against defects and deficiencies in the Work, and(3)to determine in general if the Work is being performed in a manner indicating that the Work, when fully completed, will be in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. The Architect will neither have control over or charge of, nor be responsible for, the construction means, methods, techniques, sequences or procedures, or for the safety precautions and programs in connection with the Work, since these are solely the Contractor's rights and responsibilities under the Contract Documents, except as provided in Subparagraph 3.3.1. 4.2.3 The Architect will not be responsible for the Contractor's failure to perform the Work in accordance with the requirements of the Contract Documents. The Architect will not have control over or charge of and will not be responsible for acts or omissions of the Contractor, THIS DOCUMENT HAS IMPORTANT LEGAL Subcontractors, or their agents or employees, or any other persons or entities performing CONSEQUENCES.CONSULTATION WITHAN portions of the Work. ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR 4.2.4 Communications Facilitating ontract Administration. Except as otherwise MODIFICATION.AUTHETEDAIIONOFTHIS S P ELECTRONICALLY DRAFTED AIA provided in the Contract Documents or when direct communications have been specially DOCUMENT MAY BE MADE BY USING AIA authorized,the Owner and Contractor shall endeavor to communicate with each other through DOCUMENT DOI. the Architect about matters arising out of or relating to the Contract.Communications by and with the Architect's consultants shall be through the Architect. Communications by and with This document has been approved and Subcontractors and material suppliers shall be through the Contractor. Communications by endorsed by The Associated General and with separate contractors shall be through the Owner. Contractors of America. 4.2.5 Based on the Architect's evaluations of the Contractor's Applications for Payment,the Architect will review and certify the amounts due the Contractor and will issue Certificates for Payment in such amounts. 4.2.6 The Architect will have authority to reject Work that does not conform to the Contract Documents.Whenever the Architect considers it necessary or advisable,the Architect will have authority to require inspection or testing of the Work in accordance with Subparagraphs 13.5.2 and 13.5.3,whether or not such Work is fabricated,installed or completed. However, neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect to the Contractor,Subcontractors,material and equipment suppliers,their agents or employees,or other persons or entities performing portions of the Work. 4.2.7 The Architect will review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents.The Architect's action will be taken with such reasonable promptness as to cause no delay in the Work or in the activities of the Owner,Contractor or separate contractors,while allowing sufficient time in the Architect's professional judgment to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems,all of which remain the responsibility of the Contractor as required by the Contract Documents.The Architect's review of the Contractor's submittals shall not relieve the Contractor of the 4. .-W obligations under Paragraphs 3.3, 3.5 and 3.12. The Architect's review shall not constitute f�' �'� approval of safety precautions or, unless otherwise specifically stated by the Architect, of any construction means,methods,techniques,sequences or procedures.The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. oi9e7"i"® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1911, 1915, 1918, 1925, 1937, , 1958, 9 0, y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 19 4.2.8 The Architect will prepare Change Orders and Construction Change Directives, and may authorize minor changes in the Work as provided in Paragraph 7.4. 4.2.9 The Architect will conduct inspections to determine the date or dates of Substantial Completion and the date of final completion,will receive and forward to the Owner, for the Owner's review and records,written warranties and related documents required by the Contract and assembled by the Contractor, and will issue a final Certificate for Payment upon compliance with the requirements of the Contract Documents. 4.2.10 If the Owner and Architect agree, the Architect will provide one or more project representatives to assist in carrying out the Architect's responsibilities at the site. The duties, responsibilities and limitations of authority of such project representatives shall be as set forth in an exhibit to be incorporated in the Contract Documents. 4.2.11 The Architect will interpret and decide matters concerning performance under and THIS DOCUMENT HAS IMPORTANT LEGAL P g P CONSEQUENCES.CONSULTATION WITH AN requirements of, the Contract Documents on written request of either the Owner or ATTORNEY IS ENCOURAGED WITH Contractor. The Architect's response to such requests will be made in writing within any time RESPECT TO ITS COMPLETION OR limits agreed upon or otherwise with reasonable promptness. If no agreement is made MODIFICATION.AUTHENTICATION OF THIS concerning the time within which interpretations required of the Architect shall be furnished in ELECTRONICALLY DRAFTED AIA compliance with this Paragraph 4.2,then delay shall not be recognized on account of failure by DOCUMENT MAY BE MADE BY USING AIA the Architect to furnish such interpretations until 15 days after written request is made for DOCUMENT D401. them. This document has been approved and 4.2.12 Interpretations and decisions of the Architect will be consistent with the intent of and endorsed by The Associated General reasonably inferable from the Contract Documents and will be in writing or in the form of Contractors of America. drawings. When making such interpretations and initial decisions,the Architect will endeavor to secure faithful performance by both Owner and Contractor,will not show partiality to either and will not be liable for results of interpretations or decisions so rendered in good faith. 4.2.13 The Architect's decisions on matters relating to aesthetic effect will be final if consistent with the intent expressed in the Contract Documents. 4.3 CLAIMS AND DISPUTES 4.3.1 Definition. A Claim is a demand or assertion by one of the parties seeking, as a matter of right,adjustment or interpretation of Contract terms,payment of money,extension of time or other relief with respect to the terms of the Contract.The term"Claim"also includes other disputes and matters in question between the Owner and Contractor arising out of or relating to the Contract. Claims must be initiated by written notice. The responsibility to substantiate Claims shall rest with the party making the Claim. 4.3.2 Time Limits on Claims.Claims by either party must be initiated within 21 days after occurrence of the event giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving rise to the Claim,whichever is later.Claims must be initiated by written notice to the Architect and the other party. 4.3.3 Continuing Contract Performance. Pending final resolution of a Claim except as —� otherwise agreed in writing or as provided in Subparagraph 9.7.1 and Article 14,the Contractor shall proceed diligently with performance of the Contract and the Owner shall continue to make payments in accordance with the Contract Documents. IN ,-W 4.3.4 Claims for Concealed or Unknown Conditions.If conditions are encountered at the site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (2) unknown physical 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: I's 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 20 conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, then notice by the observing party shall be given to the other party promptly before conditions are disturbed and in no event later than u days after first observance of the conditions. The Architect will promptly investigate such conditions and, if they differ materially and cause an increase or decrease in the Contractor's cost of, or time required for,performance of any part of the Work,will recommend an equitable adjustment in the Contract Sum or Contract Time,or both.If the Architect determines that the conditions at the site are not materially different from those indicated in the Contract Documents and that no change in the terms of the Contract is justified,the Architect shall so notify the Owner and Contractor in writing, stating the reasons. Claims by either party in opposition to such determination must be made within u days after the Architect has given notice of the decision. If the conditions encountered are materially different, the Contract Sum and Contract Time shall be equitably adjusted,but if the Owner and Contractor cannot agree on an adjustment in the Contract Sum or Contract Time,the adjustment shall be referred to the Architect for initial determination,subject to further proceedings pursuant to Paragraph 4.4• THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES.CONSULTATION WITH AN 4.3.5 Claims for Additional Cost. If the Contractor wishes to make Claim for an ATTORNEY IS ENCOURAGED WITH increase in the Contract Sum, written notice as provided herein shall be given before RESPECT TO ITS COMPLETION OR proceeding to execute the Work. Prior notice is not required for Claims relating to an MODIFICATION.AUTHENTICATION OF T115 emergency endangering life or property arising under Paragraph io.6. ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA 4.3.6 If the Contractor believes additional cost is involved for reasons including but not DOCUMENT D401. limited to(1)a written interpretation from the Architect,(2)an order by the Owner to stop the This document has been approved and Work where the Contractor was not at fault,(3)a written order for a minor change in the Work endorsed by The Associated General issued by the Architect,(4)failure of payment by the Owner,(5)termination of the Contract by Contractors of America. the Owner, (6) Owner's suspension or (7) other reasonable grounds, Claim shall be filed in accordance with this Paragraph 4.3. 4.3.7 Claims for Additional Time 4.3.7.1 If the Contractor wishes to make Claim for an increase in the Contract Time,written notice as provided herein shall be given. The Contractor's Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay only one Claim is necessary. 4.3.7.2 If adverse weather conditions are the basis for a Claim for additional time,such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time, could not have been reasonably anticipated and had an adverse effect on the scheduled construction. 4.3.8 Injury or Damage to Person or Property. If either party to the Contract suffers injury or damage to person or property because of an act or omission of the other party,or of others for whose acts such party is legally responsible,written notice of such injury or damage, whether or not insured,shall be given to the other party within a reasonable time not exceeding 21 days after discovery. The notice shall provide sufficient detail to enable the other party to investigate the matter. 4.3.9 If unit prices are stated in the Contract Documents or subsequently agreed upon,and SM if quantities originally contemplated are materially changed in a proposed Change Order or Construction Change Directive so that application of such unit prices to quantities of Work �„ , proposed will cause substantial inequity to the Owner or Contractor,the applicable unit prices f++In shall be equitably adjusted. 01997 AIAO AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1925, 1958, by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 1213/2002. AIA License Number 1008538, which expires on 9/312003. 21 4.3.10 Claims for Consequential Damages. The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract. This mutual waiver includes: 1 damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and reputation, and for loss of management or employee productivity or of the services of such persons;and .2 damages incurred by the Contractor for principal office expenses including the compensation of personnel stationed there, for losses of financing, business and reputation, and for loss of profit except anticipated profit arising directly from the Work. This mutual waiver is applicable,without limitation,to all consequential damages due to either party's termination in accordance with Article 14.Nothing contained in this Subparagraph 4.3.10 shall be deemed to preclude an award of liquidated direct damages, when applicable, in accordance with the requirements of the Contract Documents. THIS DOCUMENT HAS IMPORTANT LEGAL 4.4 RESOLUTION OF CLAIMS AND DISPUTES CONSEQUENCES.CONSULTATION WITHAN ATTORNEY ATTORNEY IS ENCOURAGED WITH 4.4.1 Decision of Architect. Claims,including those alleging an error or omission by the RESPECT TO ITS COMPLETION OR Architect but excluding those arising under Paragraphs 10.3 through 10.5, shall be referred MODIFICATION.AUTHENTICATION OF THIS initially to the Architect for decision.An initial decision by the Architect shall be required as a ELECTRONICALLY DRAFTED AIA condition precedent to mediation,arbitration or litigation of all Claims between the Contractor DOCUMENT MAY BE MADE BY USING AIA and Owner arising prior to the date final payment is due,unless 3o days have passed after the DOCUMENT D401. Claim has been referred to the Architect with no decision having been rendered by the Architect. The Architect will not decide disputes between the Contractor and persons or This document has been approved and entities other than the Owner. endorsed by The Associated General Contractors of America. 4.4.2 The Architect will review Claims and within ten days of the receipt of the Claim take one or more of the following actions: (1)request additional supporting data from the claimant or a response with supporting data from the other party, (2) reject the Claim in whole or in part, (3) approve the Claim, (4) suggest a compromise, or (5) advise the parties that the Architect is unable to resolve the Claim if the Architect lacks sufficient information to evaluate the merits of the Claim or if the Architect concludes that, in the Architect's sole discretion,it would be inappropriate for the Architect to resolve the Claim. 4.4.3 In evaluating Claims,the Architect may,but shall not be obligated to,consult with or seek information from either party or from persons with special knowledge or expertise who may assist the Architect in rendering a decision. The Architect may request the Owner to authorize retention of such persons at the Owner's expense. 4.4.4 If the Architect requests a party to provide a response to a Claim or to furnish additional supporting data, such party shall respond, within ten days after receipt of such request, and shall either provide a response on the requested supporting data, advise the Architect when the response or supporting data will be furnished or advise the Architect that no supporting data will be furnished.Upon receipt of the response or supporting data,if any,the Architect will either reject or approve the Claim in whole or in part. 4.4.5 The Architect will approve or reject Claims by written decision,which shall state the reasons therefor and which shall notify the parties of any change in the Contract Sum or Contract Time or both.The approval or rejection of a Claim by the Architect shall be final and binding on the parties but subject to mediation and arbitration. IN 4.4.6 When a written decision of the Architect states that(1)the decision is final but subject to mediation and arbitration and (2) a demand for arbitration of a Claim covered by such decision must be made within 3o days after the date on which the party making the demand 01997 AIA® receives the final written decision, then failure to demand arbitration within said 30 days' AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright g 63, 1966, 1967, 1970, 1976, 1987, 0 1997 by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 22 AWN 110q& period shall result in the Architect's decision becoming final and binding upon the Owner and Contractor. If the Architect renders a decision after arbitration proceedings have been initiated, such decision may be entered as evidence, but shall not supersede arbitration proceedings unless the decision is acceptable to all parties concerned. 4.4.7 Upon receipt of a Claim against the Contractor or at any time thereafter, the Architect or the Owner may,but is not obligated to,notify the surety,if any,of the nature and amount of the Claim.If the Claim relates to a possibility of a Contractor's default,the Architect or the Owner may,but is not obligated to, notify the surety and request the surety's assistance in resolving the controversy. 4.4.8 If a Claim relates to or is the subject of a mechanic's lien, the party asserting such Claim may proceed in accordance with applicable law to comply with the lien notice or filing deadlines prior to resolution of the Claim by the Architect,by mediation or by arbitration. 4.5 MEDIATION THIS DOCUMENT HAS IMPORTANT LEGAL 4.5.1 An Claim arising out of or related to the Contract,except Claims relating to aesthetic CONSEQUENCES.ENCOURAGED WITH WITH AN Any g P g ATTORNEY IS ENCOURAGED WITH effect and except those waived as provided for in Subparagraphs 4.3.10,9.10.4 and 9.10.5 shall, RESPECT TO ITS COMPLETION OR after initial decision by the Architect or 3o days after submission of the Claim to the Architect, MODIFICATION.AUTHENTICATION OF THIS be subject to mediation as a condition precedent to arbitration or the institution of legal or ELECTRONICALLY DRAFTED AIA equitable proceedings by either party. DOCUMENT MAY BE MADE BY USING AIA DOCUMENT MI. 4.5.2 The parties shall endeavor to resolve their Claims by mediation which, unless the parties mutually agree otherwise, shall be in accordance with the Construction Industry This document has been approved and Mediation Rules of the American Arbitration Association currently in effect. Request for endorsed by The Associated General mediation shall be filed in writing with the other party to the Contract and with the American Contractors of America. Arbitration Association.The request may be made concurrently with the filing of a demand for arbitration but, in such event, mediation shall proceed in advance of arbitration or legal or equitable proceedings,which shall be stayed pending mediation for a period of 6o days from the date of filing,unless stayed for a longer period by agreement of the parties or court order. 4.5.3 The parties shall share the mediator's fee and any filing fees equally. The mediation shall be held in the place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. 4.6 ARBITRATION 4.6.1 Any Claim arising out of or related to the Contract,except Claims relating to aesthetic effect and except those waived as provided for in Subparagraphs 4.3.10,9.10.4 and 9.10.5,shall, after decision by the Architect or 3o days after submission of the Claim to the Architect, be subject to arbitration. Prior to arbitration, the parties shall endeavor to resolve disputes by mediation in accordance with the provisions of Paragraph 4.5• 4.6.2 Claims not resolved by mediation shall be decided by arbitration which, unless the parties mutually agree otherwise, shall be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association currently in effect.The demand for arbitration shall be filed in writing with the other party to the Contract and with the American '= Arbitration Association,and a copy shall be filed with the Architect. 4.6.3 A demand for arbitration shall be made within the time limits specified in Subparagraphs 4.4.6 and 4.6.1 as applicable,and in other cases within a reasonable time after the i,.1�.;■'» Claim has arisen, and in no event shall it be made after the date when institution of legal or equitable proceedings based on such Claim would be barred by the applicable statute of limitations as determined pursuant to Paragraph 13.7. 01"7"I"® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 5, � y ThF CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 121312002. AIA License Number 1008538, which expires on 9/3/2003. 23 4.6.4 Limitation on Consolidation or Joinder. No arbitration arising out of or relating to the Contract shall include,by consolidation or joinder or in any other manner,the Architect, the Architect's employees or consultants, except by written consent containing specific reference to the Agreement and signed by the Architect, Owner, Contractor and any other person or entity sought to be joined.No arbitration shall include,by consolidation or joinder or in any other manner, parties other than the Owner, Contractor, a separate contractor as described in Article 6 and other persons substantially involved in a common question of fact or law whose presence is required if complete relief is to be accorded in arbitration. No person or entity other than the Owner,Contractor or a separate contractor as described in Article 6 shall be included as an original third party or additional third party to an arbitration whose interest or responsibility is insubstantial.Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of a Claim not described therein or with a person or entity not named or described therein. The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by parties to the Agreement shall be specifically enforceable under applicable law in any court having jurisdiction thereof. THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES.CONSULTATION WITH AN 4.6.5 Claims and Timely Assertion of Claims. The party filing a notice of demand for ATTORNEY IS ENCOURAGED WITH arbitration must assert in the demand all Claims then known to that party on which arbitration RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF TFNS 1S permitted to be demanded. ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA 4.6.6 Judgment on Final Award. The award rendered by the arbitrator or arbitrators DOCUMENTWI. shall be final,and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. This document has been approved and endorsed by The Associated General ARTICLE 5 SUBCONTRACTORS Contractors of America. 5.1 DEFINITIONS 5.1.1 A Subcontractor is a person or entity who has a direct contract with the Contractor to perform a portion of the Work at the site.The term "Subcontractor"is referred to throughout the Contract Documents as if singular in number and means a Subcontractor or an authorized representative of the Subcontractor. The term "Subcontractor" does not include a separate contractor or subcontractors of a separate contractor. 5.1.2 A Sub-subcontractor is a person or entity who has a direct or indirect contract with a Subcontractor to perform a portion of the Work at the site. The term "Sub-subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Sub- subcontractor or an authorized representative of the Sub-subcontractor. 5.2 AWARD OF SUBCONTRACTS AND OTHER CONTRACTS FOR PORTIONS OF THE WORK 5.2.1 Unless otherwise stated in the Contract Documents or the bidding requirements,the Contractor, as soon as practicable after award of the Contract, shall furnish in writing to the Owner through the Architect the names of persons or entities (including those who are to furnish materials or equipment fabricated to a special design) proposed for each principal portion of the Work. The Architect will promptly reply to the Contractor in writing stating whether or not the Owner or the Architect,after due investigation,has reasonable objection to any such proposed person or entity. Failure of the Owner or Architect to reply promptly shall constitute notice of no reasonable objection. 5.2.2 The Contractor shall not contract with a proposed person or entity to whom the '�, ,-W Owner or Architect has made reasonable and timely objection. The Contractor shall not be -15;, 'ir required to contract with anyone to whom the Contractor has made reasonable objection. 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1966, 1967, 1970, 1976, 1987, Q 1997 by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject The violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 24 5.2.3 If the Owner or Architect has reasonable objection to a person or entity proposed by the Contractor,the Contractor shall propose another to whom the Owner or Architect has no reasonable objection. If the proposed but rejected Subcontractor was reasonably capable of performing the Work,the Contract Sum and Contract Time shall be increased or decreased by the difference, if any, occasioned by such change, and an appropriate Change Order shall be issued before commencement of the substitute Subcontractor's Work. However,no increase in the Contract Sum or Contract Time shall be allowed for such change unless the Contractor has acted promptly and responsively in submitting names as required. 5.2.4 The Contractor shall not change a Subcontractor,person or entity previously selected if the Owner or Architect makes reasonable objection to such substitute. 5.3 SUBCONTRACTUAL RELATIONS 5.3.1 By appropriate agreement,written where legally required for validity,the Contractor shall require each Subcontractor, to the extent of the Work to be performed by the THIS DOCUMENT HAS IMPORTANT LEGAL Subcontractor, to be bound to the Contractor by terms of the Contract Documents, and to CONSEQUENCES.CONSULTATION WITHAN assume toward the Contractor all the obligations and responsibilities, including the ATTORNEY 15 ENCOURAGED WITH responsibility for safety of the Subcontractor's Work, which the Contractor, by these RESPECT TO ITS COMPLETION OR Documents, assumes toward the Owner and Architect. Each subcontract agreement shall MODIFICATION.AUTHENTICATION OF THIS preserve and protect the rights of the Owner and Architect under the Contract Documents with ELECTRONICALLY DRAFTED AIA respect to the Work to be performed by the Subcontractor so that subcontracting thereof will DOCUMENT MAY BE MADE BY USING AIA not prejudice such rights, and shall allow to the Subcontractor, unless specifically provided DOCUMENT D401. otherwise in the subcontract agreement,the benefit of all rights, remedies and redress against the Contractor that the Contractor,by the Contract Documents,has against the Owner.Where This document has been approved and appropriate, the Contractor shall require each Subcontractor to enter into similar agreements endorsed by The Associated General with Sub-subcontractors.The Contractor shall make available to each proposed Subcontractor, Contractors of America. prior to the execution of the subcontract agreement, copies of the Contract Documents to which the Subcontractor will be bound, and, upon written request of the Subcontractor, identify to the Subcontractor terms and conditions of the proposed subcontract agreement which may be at variance with the Contract Documents. Subcontractors will similarly make copies of applicable portions of such documents available to their respective proposed Sub- subcontractors. 5.4 CONTINGENT ASSIGNMENT OF SUBCONTRACTS 5.4.1 Each subcontract agreement for a portion of the Work is assigned by the Contractor to the Owner provided that: 1 assignment is effective only after termination of the Contract by the Owner for cause pursuant to Paragraph 14.2 and only for those subcontract agreements which the Owner accepts by notifying the Subcontractor and Contractor in writing;and .2 assignment is subject to the prior rights of the surety,if any,obligated under bond relating to the Contract. 5.4.2 Upon such assignment, if the Work has been suspended for more than 3o days, the Subcontractor's compensation shall be equitably adjusted for increases in cost resulting from the suspension. ARTICLE 6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS 6.1 OWNER'S RIGHT TO PERFORM CONSTRUCTION AND TO AWARD SEPARATE CONTRACTS . .� 6.1.1 The Owner reserves the right to perform construction or operations related to the Project with the Owners own forces,and to award separate contracts in connection with other portions of the Project or other construction or operations on the site under Conditions of the 01997 AIA® Contract identical or substantially similar to these including those portions related to insurance AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright y ThF,CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 1202002. AIA License Number 1008538, which expires on 9/3/2003. 25 AWN and waiver of subrogation. If the Contractor claims that delay or additional cost is involved because of such action by the Owner, the Contractor shall make such Claim as provided in Paragraph 4.3• 6.1.2 When separate contracts are awarded for different portions of the Project or other construction or operations on the site, the term "Contractor" in the Contract Documents in each case shall mean the Contractor who executes each separate Owner-Contractor Agreement. 6.1.3 The Owner shall provide for coordination of the activities of the Owner's own forces and of each separate contractor with the Work of the Contractor, who shall cooperate with them. The Contractor shall participate with other separate contractors and the Owner in reviewing their construction schedules when directed to do so. The Contractor shall make any revisions to the construction schedule deemed necessary after a joint review and mutual agreement. The construction schedules shall then constitute the schedules to be used by the Contractor,separate contractors and the Other until subsequently revised. THIS DOCUMENT HAS IMPORTANT LEGAL 6.1.4 Unless otherwise provided in the Contract Documents, when the Owner performs CONSEQUENCES.CONSULTATION WITHAN construction or operations related to the Project with the Owner's own forces,the Owner shall ATTORNEY 15 ENCOURAGED WITH be deemed to be subject to the same obligations and to have the same rights which apply to the RESPECT TO ITS COMPLETION OR Contractor under the Conditions of the Contract, including, without excluding others, those MODIFICATION.AUTHENTICATION OF TH15 g g ELECTRONICALLY DRAfTED AIA stated in Article 3,this Article 6 and Articles io,11 and 12. DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. 6.2 MUTUAL RESPONSIBILITY 6.2.1 The Contractor shall afford the Owner and separate contractors reasonable This document has been approved and opportunity for introduction and storage of their materials and equipment and performance of endorsed by The Associated General their activities,and shall connect and coordinate the Contractor's construction and operations Contractors of America. with theirs as required by the Contract Documents. 6.2.2 If part of the Contractor's Work depends for proper execution or results upon construction or operations by the Owner or a separate contractor,the Contractor shall,prior to proceeding with that portion of the Work, promptly report to the Architect apparent discrepancies or defects in such other construction that would render it unsuitable for such proper execution and results. Failure of the Contractor so to report shall constitute an acknowledgment that the Owners or separate contractor's completed or partially completed construction is fit and proper to receive the Contractor's Work,except as to defects not then reasonably discoverable. 6.2.3 The Owner shall be reimbursed by the Contractor for costs incurred by the Owner which are payable to a separate contractor because of delays, improperly timed activities or defective construction of the Contractor.The Owner shall be responsible to the Contractor for costs incurred by the Contractor because of delays,improperly timed activities,damage to the Work or defective construction of a separate contractor. 6.2.4 The Contractor shall promptly remedy damage wrongfully caused by the Contractor to completed or partially completed construction or to property of the Owner or separate contractors as provided in Subparagraph 10.2.5. 6.2.5 The Owner and each separate contractor shall have the same responsibilities for cutting and patching as are described for the Contractor in Subparagraph 3.14. 6.3 OWNER'S RIGHT TO CLEAN UP ;; ,; 6.3.1 If a dispute arises among the Contractor,separate contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1925, 1951, 1958, 1961, 1963, 1966, 1967, 1970, 1976, 1987, 0 1997 by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/3/2002. AIA License Number 1008538, which expires on 9/312003. 26 AWN lo% %0 1111110 area free from waste materials and rubbish, the Owner may clean up and the Architect will allocate the cost among those responsible. ARTICLE 7 CHANGES IN THE WORK 7.1 GENERAL 7.1.1 Changes in the Work may be accomplished after execution of the Contract, and without invalidating the Contract, by Change Order, Construction Change Directive or order for a minor change in the Work,subject to the limitations stated in this Article 7 and elsewhere in the Contract Documents. 7.1.2 A Change Order shall be based upon agreement among the Owner, Contractor and Architect; a Construction Change Directive requires agreement by the Owner and Architect and may or may not be agreed to by the Contractor;an order for a minor change in the Work may be issued by the Architect alone. 7.1.3 Changes in the Work shall be performed under applicable provisions of the Contract THIS DOCUMENT HAS IMPORTANT LEGAL g P PP P CONSEQUENCES.CONSULTATION WITH AN Documents, and the Contractor shall proceed promptly, unless otherwise provided in the ATTORNEY IS ENCOURAGED WITH Change Order,Construction Change Directive or order for a minor change in the Work. RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF THS 7.2 CHANGE ORDERS ELECTRONICALLY DRAFTED AIA 7.2.1 A Change Order is a written instrument prepared by the Architect and signed by the DOCUMENT MAY BE MADE BY USING AIA Owner,Contractor and Architect,stating their agreement upon all of the following: DOCUMENT MI. This document has been approved and .1 change in the Work; endorsed by The Associated General .2 the amount of the adjustment,if any,in the Contract Sum;and Contractors of America. .3 the extent of the adjustment,if any,in the Contract Time. 7.2.2 Methods used in determining adjustments to the Contract Sum may include those listed in Subparagraph 7.3.3• 7.3 CONSTRUCTION CHANGE DIRECTIVES 7.3.1 A Construction Change Directive is a written order prepared by the Architect and signed by the Owner and Architect, directing a change in the Work prior to agreement on adjustment, if any, in the Contract Sum or Contract Time, or both. The Owner may by Construction Change Directive,without invalidating the Contract,order changes in the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the Contract Sum and Contract Time being adjusted accordingly. 7.3.2 A Construction Change Directive shall be used in the absence of total agreement on the terms of a Change Order. 7.3.3 If the Construction Change Directive provides for an adjustment to the Contract Sum, the adjustment shall be based on one of the following methods: .1 mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluation; �! .2 unit prices stated in the Contract Documents or subsequently agreed upon; .3 cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee;or .4 as provided in Subparagraph 7.3.6. . 7.3.4 Upon receipt of a Construction Change Directive, the Contractor shall promptly proceed with the change in the Work involved and advise the Architect of the Contractor's 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1951, by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 27 agreement or disagreement with the method, if any, provided in the Construction Change Directive for determining the proposed adjustment in the Contract Sum or Contract Time. 7.3.5 A Construction Change Directive signed by the Contractor indicates the agreement of the Contractor therewith, including adjustment in Contract Sum and Contract Time or the method for determining them. Such agreement shall be effective immediately and shall be recorded as a Change Order. 7.3.6 If the Contractor does not respond promptly or disagrees with the method for adjustment in the Contract Sum, the method and the adjustment shall be determined by the Architect on the basis of reasonable expenditures and savings of those performing the Work attributable to the change,including,in case of an increase in the Contract Sum,a reasonable allowance for overhead and profit. In such case, and also under Clause 7.3.3.3, the Contractor shall keep and present, in such form as the Architect may prescribe, an itemized accounting together with appropriate supporting data. Unless otherwise provided in the Contract Documents,costs for the purposes of this Subparagraph 7.3.6 shall be limited to the following: THIS DOCUMENT HAS IMPORTANT LEGAL 1 costs of labor, including social security, old age and unemployment insurance, CONSEQUENCES.CONSULTATION WITH AN fringe benefits required b y agreement or custom, and workers' compensation ATTORNEY 15 ENCOURAGED WITH RESPECT TO ITS COMPLETION OR insurance; MODIFICATION.AUTHENTICATION OF THIS .2 costs of materials, supplies and equipment, including cost of transportation, ELECTRONICALLY DRAFTED AIA whether incorporated or consumed; DOCUMENT MAY BE MADE BY USING AIA .3 rental costs of machinery and equipment,exclusive of hand tools,whether rented DOCUMENT D401. from the Contractor or others; .4 costs of premiums for all bonds and insurance, permit fees, and sales, use or This document has been approved and similar taxes related to the Work;and endorsed by The Associated General .5 additional costs of supervision and field office personnel directly attributable to Contractors of America. the change. 7.3.7 The amount of credit to be allowed by the Contractor to the Owner for a deletion or change which results in a net decrease in the Contract Sum shall be actual net cost as confirmed by the Architect. When both additions and credits covering related Work or substitutions are involved in a change,the allowance for overhead and profit shall be figured on the basis of net increase,if any,with respect to that change. 7.3.8 Pending final determination of the total cost of a Construction Change Directive to the Owner, amounts not in dispute for such changes in the Work shall be included in Applications for Payment accompanied by a Change Order indicating the parties' agreement with part or all of such costs.For any portion of such cost that remains in dispute,the Architect will make an interim determination for purposes of monthly certification for payment for those costs.That determination of cost shall adjust the Contract Sum on the same basis as a Change Order, subject to the right of either party to disagree and assert a claim in accordance with Article 4. 7.3.9 When the Owner and Contractor agree with the determination made by the Architect concerning the adjustments in the Contract Sum and Contract Time, or otherwise reach agreement upon the adjustments, such agreement shall be effective immediately and shall be recorded by preparation and execution of an appropriate Change Order. 7.4 MINOR CHANGES IN THE WORK 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents.Such changes shall be effected by written order and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders 01997 AIA® promptly. AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE s opyrig t 9 9 9 1970, 9 8 , y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/312003. 28 AWN ARTICLE 8 TIME 8.1 DEFINITIONS 8.1.1 Unless otherwise provided,Contract Time is the period of time, including authorized adjustments,allotted in the Contract Documents for Substantial Completion of the Work. 8.1.2 The date of commencement of the Work is the date established in the Agreement. 8.1.3 The date of Substantial Completion is the date certified by the Architect in accordance with Paragraph 9.8. 8.1.4 The term "day" as used in the Contract Documents shall mean calendar day unless otherwise specifically defined. 8.2 PROGRESS AND COMPLETION THIS DOCUMENT HAS IMPORTANT LEGAL 8.2.1 Time limits stated in the Contract Documents are of the essence of the Contract. By CONSEOUENCES.CONSULTATION WITHAN executing the Agreement the Contractor confirms that the Contract Time is a reasonable ATTORNEY IS ENCOURAGED WITH period for performing the Work. RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF THIS 8.2.2 The Contractor shall not knowingly,except b agreement or instruction of the Owner ELECTRONICALLY DRAFTED AIA P Y g DOCUMENT MAY BE MADE BY USING AIA in writing, prematurely commence operations on the site or elsewhere prior to the effective DOCUMENT D401. date of insurance required by Article a to be furnished by the Contractor and Owner.The date of commencement of the Work shall not be changed by the effective date of such insurance. This document has been approved and Unless the date of commencement is established by the Contract Documents or a notice to endorsed by The Associated General proceed given by the Owner,the Contractor shall notify the Owner in writing not less than five Contractors of America. days or other agreed period before commencing the Work to permit the timely filing of mortgages,mechanic's liens and other security interests. 8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion within the Contract Time. 8.3 DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by an act or neglect of the Owner or Architect, or of an employee of either, or of a separate contractor employed by the Owner, or by changes ordered in the Work,or by labor disputes, fire,unusual delay in deliveries,unavoidable casualties or other causes beyond the Contractor's control, or by delay authorized by the Owner pending mediation and arbitration or by other causes which the Architect determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine. 8.3.2 Claims relating to time shall be made in accordance with applicable provisions of Paragraph 4.3• 8.3.3 This Paragraph 8.3 does not preclude recovery of damages for delay by either party under other provisions of the Contract Documents. _ ARTICLE 9 PAYMENTS AND COMPLETION 9.1 CONTRACT SUM 9.1.1 The Contract Sum is stated in the Agreement and,including authorized adjustments, is the total amount payable by the Owner to the Contractor for performance of the Work under �V +r the Contract Documents. 9.2 SCHEDULE OF VALUES 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1911, 1915, 1918, 1925, by e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/312003. 29 APN 9.2.1 Before the first Application for Payment,the Contractor shall submit to the Architect a schedule of values allocated to various portions of the Work, prepared in such form and supported by such data to substantiate its accuracy as the Architect may require.This schedule, unless objected to by the Architect, shall be used as a basis for reviewing the Contractor's Applications for Payment. 9.3 APPLICATIONS FOR PAYMENT 9.3.1 At least ten days before the date established for each progress payment,the Contractor shall submit to the Architect an itemized Application for Payment for operations completed in accordance with the schedule of values. Such application shall be notarized, if required, and supported by such data substantiating the Contractors right to payment as the Owner or Architect may require, such as copies of requisitions from Subcontractors and material suppliers,and reflecting retainage if provided for in the Contract Documents. 9.3.1.1 As provided in Subparagraph 7.3.8, such applications may include requests for THIS DOCUMENT HAS IMPORTANT LEGAL payment on account of changes in the Work which have been properly authorized by CONSEQUENCES.CONSULTATION WITHAN Construction Change Directives, or by interim determinations of the Architect, but not yet ATTORNEY IS ENCOURAGED WITH included in Change Orders. RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF THIS 9.3.1.2 Such applications may not include requests for payment for portions of the Work for ELECTRONICALLY DRAFTED AIA which the Contractor does not intend to pay to a Subcontractor or material supplier, unless DOCUMENT MAY BE MADE BY USING AIA such Work has been performed by others whom the Contractor intends to pay. DOCUMENT D401. 9.3.2 Unless otherwise provided in the Contract Documents, payments shall be made on This document has been approved and account of materials and equipment delivered and suitably stored at the site for subsequent endorsed by The Associated General incorporation in the Work. If approved in advance by the Owner, payment may similarly be Contractors of America. made for materials and equipment suitably stored off the site at a location agreed upon in writing. Payment for materials and equipment stored on or off the site shall be conditioned upon compliance by the Contractor with procedures satisfactory to the Owner to establish the Owner's title to such materials and equipment or otherwise protect the Owner's interest, and shall include the costs of applicable insurance, storage and transportation to the site for such materials and equipment stored off the site. 9.3.3 The Contractor warrants that title to all Work covered by an Application for Payment will pass to the Owner no later than the time of payment.The Contractor further warrants that upon submittal of an Application for Payment all Work for which Certificates for Payment have been previously issued and payments received from the Owner shall, to the best of the Contractor's knowledge, information and belief, be free and clear of liens, claims, security interests or encumbrances in favor of the Contractor, Subcontractors, material suppliers, or other persons or entities making a claim by reason of having provided labor, materials and equipment relating to the Work. 9.4 CERTIFICATES FOR PAYMENT 9.4.1 The Architect will,within seven days after receipt of the Contractor's Application for Payment,either issue to the Owner a Certificate for Payment,with a copy to the Contractor,for such amount as the Architect determines is properly due,or notify the Contractor and Owner in writing of the Architect's reasons for withholding certification in whole or in part as provided in Subparagraph 9.5.1. 9.4.2 The issuance of a Certificate for Payment will constitute a representation by the �A Architect to the Owner, based on the Architect's evaluation of the Work and the data comprising the Application for Payment, that the Work has progressed to the point indicated and that, to the best of the Architect's knowledge, information and belief, the quality of the Work is in accordance with the Contract Documents.The foregoing representations are subject 01997 AIAO to an evaluation of the Work for conformance with the Contract Documents upon Substantial AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1966, 1967, 1970, 1976, 1987, 0 1997 by e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/312003. 30 11111110 W Completion, to results of subsequent tests and inspections, to correction of minor deviations from the Contract Documents prior to completion and to specific qualifications expressed by the Architect.The issuance of a Certificate for Payment will further constitute a representation that the Contractor is entitled to payment in the amount certified. However,the issuance of a Certificate for Payment will not be a representation that the Architect has(i) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work, (2) reviewed construction means, methods, techniques, sequences or procedures, (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the Owner to substantiate the Contractor's right to payment, or (4) made examination to ascertain how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. 9.5 DECISIONS TO WITHHOLD CERTIFICATION 9.5.1 The Architect may withhold a Certificate for Payment in whole or in part, to the extent reasonably necessary to protect the Owner, if in the Architect's opinion the representations to the Owner required by Subparagraph 9.4.2 cannot be made.If the Architect THIS DOCUMENT HAS IMPORTANT LEGAL is unable to certify payment in the amount of the Application, the Architect will notify the CONSEQUENCES.CONSULTATION wHAN Contractor and Owner as provided in Subparagraph 9.4.1. If the Contractor and Architect ATTORNEY 15 ENCOURAGED WITH cannot agree on a revised amount,the Architect will promptly issue a Certificate for Payment RESPECT TO ITS COMPLETION OR for the amount for which the Architect is able to make such representations to the Owner.The MODIFICATION.AUTHENTICATION OF THIS Architect may also withhold a Certificate for Payment or,because of subsequently discovered ELECTRONICALLY DRAFTED AIA Y Ym q Y DOCUMENT MAY BE MADE BY USING AIA evidence,may nullify the whole or a part of a Certificate for Payment previously issued,to such DOCUMENT D401. extent as may be necessary in the Architect's opinion to protect the Owner from loss for which the Contractor is responsible, including loss resulting from acts and omissions described in This document has been approved and Subparagraph 3.3.2,because of endorsed by The Associated General .1 defective Work not remedied; Contractors of America. .2 third party claims filed or reasonable evidence indicating probable filing of such claims unless security acceptable to the Owner is provided by the Contractor; .3 failure of the Contractor to make payments properly to Subcontractors or for labor,materials or equipment; .4 reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum; .5 damage to the Owner or another contractor; .6 reasonable evidence that the Work will not be completed within the Contract Time, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay;or .7 persistent failure to cant' out the Work in accordance with the Contract Documents. 9.5.2 When the above reasons for withholding certification are removed, certification will be made for amounts previously withheld. 9.6 PROGRESS PAYMENTS 9.6.1 After the Architect has issued a Certificate for Payment, the Owner shall make payment in the manner and within the time provided in the Contract Documents,and shall so notify the Architect. �s 9.6.2 The Contractor shall promptly pay each Subcontractor, upon receipt of payment from the Owner,out of the amount paid to the Contractor on account of such Subcontractor's portion of the Work,the amount to which said Subcontractor is entitled,reflecting percentages actually retained from payments to the Contractor on account of such Subcontractors portion of the Work.The Contractor shall,by appropriate agreement with each Subcontractor,require each Subcontractor to make payments to Sub-subcontractors in a similar manner. 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/312003. 31 9.6.3 The Architect will,on request, furnish to a Subcontractor, if practicable,information regarding percentages of completion or amounts applied for by the Contractor and action taken thereon by the Architect and Owner on account of portions of the Work done by such Subcontractor. 9.6.4 Neither the Owner nor Architect shall have an obligation to pay or to see to the payment of money to a Subcontractor except as may otherwise be required by law. 9.6.5 Payment to material suppliers shall be treated in a manner similar to that provided in Subparagraphs 9.6.2,9.6.3 and 9.6.4. 9.6.6 A Certificate for Payment,a progress payment,or partial or entire use or occupancy of the Project by the Owner shall not constitute acceptance of Work not in accordance with the Contract Documents. 9.6.7 Unless the Contractor provides the Owner with a payment bond in the full penal sum THIS DOCUMENT HAS IMPORTANT LEGAL P P Yin P CONSEQUENCES.CONSULTATION WITH AN of the Contract Sum, payments received by the Contractor for Work properly performed by ATTORNEY IS ENCOURAGED WITH Subcontractors and suppliers shall be held by the Contractor for those Subcontractors or RESPECT TO ITS COMPLETION OR suppliers who performed Work or furnished materials, or both, under contract with the MODIFICATION.AUTHENTICATION OF THIS Contractor for which payment was made by the Owner.Nothing contained herein shall require ELECTRONICALLY DRAFTED AIA money to be placed in a separate account and not commingled with money of the Contractor, DOCUMENT MAY BE MADE BY USING AIA shall create any fiduciary liability or tort liability on the part of the Contractor for breach of DOCUMENT D401. trust or shall entitle any person or entity to an award of punitive damages against the Contractor for breach of the requirements of this provision. This document has been approved and endorsed by The Associated General 9.7 FAILURE OF PAYMENT Contractors of America. 9.7.1 If the Architect does not issue a Certificate for Payment, through no fault of the Contractor,within seven days after receipt of the Contractor's Application for Payment, or if the Owner does not pay the Contractor within seven days after the date established in the Contract Documents the amount certified by the Architect or awarded by arbitration,then the Contractor may, upon seven additional days' written notice to the Owner and Architect,stop the Work until payment of the amount owing has been received. The Contract Time shall be extended appropriately and the Contract Sum shall be increased by the amount of the Contractor's reasonable costs of shut-down,delay and start-up,plus interest as provided for in the Contract Documents. 9.8 SUBSTANTIAL COMPLETION 9.8.1 Substantial Completion is the stage in the progress of the Work when the Work or designated portion thereof is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. 9.8.2 When the Contractor considers that the Work,or a portion thereof which the Owner agrees to accept separately,is substantially complete,the Contractor shall prepare and submit to the Architect a comprehensive list of items to be completed or corrected prior to final payment. Failure to include an item on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. 9.8.3 Upon receipt of the Contractor's list, the Architect will make an inspection to determine whether the Work or designated portion thereof is substantially complete. If the Architect's inspection discloses any item, whether or not included on the Contractor's list, which is not sufficiently complete in accordance with the Contract Documents so that the �,l+�1i•�.� Owner can occupy or utilize the Work or designated portion thereof for its intended use,the Contractor shall, before issuance of the Certificate of Substantial Completion, complete or 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 5, 1918, 1925, 1937, 1951, 1958, 9 9 9 , 9 9 y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 32 AWN correct such item upon notification by the Architect. In such case, the Contractor shall then submit a request for another inspection by the Architect to determine Substantial Completion. 9.8.4 When the Work or designated portion thereof is substantially complete,the Architect will prepare a Certificate of Substantial Completion which shall establish the date of Substantial Completion, shall establish responsibilities of the Owner and Contractor for security, maintenance, heat, utilities, damage to the Work and insurance, and shall fix the time within which the Contractor shall finish all items on the list accompanying the Certificate.Warranties required by the Contract Documents shall commence on the date of Substantial Completion of the Work or designated portion thereof unless otherwise provided in the Certificate of Substantial Completion. 9.8.5 The Certificate of Substantial Completion shall be submitted to the Owner and Contractor for their written acceptance of responsibilities assigned to them in such Certificate. Upon such acceptance and consent of surety, if any, the Owner shall make payment of retainage applying to such Work or designated portion thereof.Such payment shall be adjusted THIS DOCUMENT HAS IMPORTANT LEGAL for Work that is incomplete or not in accordance with the requirements of the Contract CONSEQUENCES.CONSULTATION WITH AN Documents. ATTORNEY 15 ENCOURAGED WITH RESPECT TO ITS COMPLETION OR 9.9 PARTIAL OCCUPANCY OR USE MODIFICATION.AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA 9.9.1 The Owner may occupy or use any completed or partially completed portion of the DOCUMENT MAY BE MADE BY U51NGAIA Work at any stage when such portion is designated by separate agreement with the Contractor, DOCUMENT D401. provided such occupancy or use is consented to by the insurer as required under Clause n.4.1.5 and authorized by public authorities having jurisdiction over the Work.Such partial occupancy This document has been approved and or use may commence whether or not the portion is substantially complete, provided the endorsed by The Associated General Owner and Contractor have accepted in writing the responsibilities assigned to each of them Contractors of America. for payments,retainage,if any,security,maintenance,heat,utilities,damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete,the Contractor shall prepare and submit a list to the Architect as provided under Subparagraph 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work shall be determined by written agreement between the Owner and Contractor or, if no agreement is reached,by decision of the Architect. 9.9.2 Immediately prior to such partial occupancy or use, the Owner, Contractor and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. 9.9.3 Unless otherwise agreed upon,partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents. 9.10 FINAL COMPLETION AND FINAL PAYMENT 9.10.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment,the Architect will promptly make such inspection and,when the Architect finds the Work acceptable under the Contract '� Documents and the Contract fully performed, the Architect will promptly issue a final Certificate for Payment stating that to the best of the Architect's knowledge,information and belief, and on the basis of the Architect's on-site visits and inspections, the Work has been completed in accordance with terms and conditions of the Contract Documents and that the f . . entire balance found to be due the Contractor and noted in the final Certificate is due and payable. The Architect's final Certificate for Payment will constitute a further representation that conditions listed in Subparagraph 9.10.2 as precedent to the Contractor's being entitled to 01997 AIA® final payment have been fulfilled. AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1987, 0 1997 by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 1202002. AIA License Number 1008538, which expires on 9/3/2003. 33 9.10.2 Neither final payment nor any remaining retained percentage shall become due until the Contractor submits to the Architect (i) an affidavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner's property might be responsible or encumbered(less amounts withheld by Owner)have been paid or otherwise satisfied, (2) a certificate evidencing that insurance required by the Contract Documents to remain in force after final payment is currently in effect and will not be canceled or allowed to expire until at least 3o days' prior written notice has been given to the Owner, (3) a written statement that the Contractor knows of no substantial reason that the insurance will not be renewable to cover the period required by the Contract Documents, (4) consent of surety, if any, to final payment and (5), if required by the Owner, other data establishing payment or satisfaction of obligations, such as receipts, releases and waivers of liens,claims,security interests or encumbrances arising out of the Contract,to the extent and in such form as may be designated by the Owner.If a Subcontractor refuses to furnish a release or waiver required by the Owner,the Contractor may furnish a bond satisfactory to the Owner to indemnify the Owner against such lien. If such lien remains unsatisfied after payments are THIS DOCUMENT HAS IMPORTANT LEGAL made,the Contractor shall refund to the Owner all money that the Owner may be compelled to CONSEOUENCES.CONSULTATION WITH AN pay in discharging such lien,including all costs and reasonable attorneys'fees. ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR 9.10.3 If, after Substantial Completion of the Work, final completion thereof is materially MODIFICATION.AUTHENTICATION OF TMS delayed through no fault of the Contractor or by issuance of Change Orders affecting final ELECTRONICALLY DRAFTED AIA completion, and the Architect so confirms, the Owner shall, upon application by the DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the This document has been approved and remaining balance for Work not fully completed or corrected is less than retainage stipulated in endorsed by The Associated General the Contract Documents, and if bonds have been furnished, the written consent of surety to Contractors of America. payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under terms and conditions governing final payment, except that it shall not constitute a waiver of claims. 9.10.4 The making of final payment shall constitute a waiver of Claims by the Owner except those arising from: 1 liens,Claims, security interests or encumbrances arising out of the Contract and unsettled; .2 failure of the Work to comply with the requirements of the Contract Documents; or .3 terms of special warranties required by the Contract Documents. 9.10.5 Acceptance of final payment by the Contractor, a Subcontractor or material supplier shall constitute a waiver of claims by that payee except those previously made in writing and identified by that payee as unsettled at the time of final Application for Payment. ARTICLE 10 PROTECTION OF PERSONS AND PROPERTY 10.1 SAFETY PRECAUTIONS AND PROGRAMS 10.1.1 The Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the performance of the Contract. 10.2 SAFETY OF PERSONS AND PROPERTY 10.2.1 The Contractor shall take reasonable precautions for safety of, and shall provide , _ reasonable protection to prevent damage,injury or loss to: .1 employees on the Work and other persons who may be affected thereby; 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE • opyrig t 1911, 1915, 1918, 1951, 1958, 9 by e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/31`2002. AIA License Number 1008538, which expires on 9/3/2003. 34 .2 the Work and materials and equipment to be incorporated therein, whether in storage on or off the site,under care,custody or control of the Contractor or the Contractor's Subcontractors or Sub-subcontractors;and .3 other property at the site or adjacent thereto,such as trees,shrubs, lawns,walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction. 10.2.2 The Contractor shall give notices and comply with applicable laws, ordinances, rules, regulations and lawful orders of public authorities bearing on safety of persons or property or their protection from damage,injury or loss. 10.2.3 The Contractor shall erect and maintain, as required by existing conditions and performance of the Contract,reasonable safeguards for safety and protection,including posting danger signs and other warnings against hazards,promulgating safety regulations and notifying owners and users of adjacent sites and utilities. THIS DOCUMENT HAS IMPORTANT LEGAL 10.2.4 When use or storage of explosives or other hazardous materials or a ui ment or CONSEQUENCES.ENCOURAGED WITH AN q P ATTORNEY IS ENCOURAGED WITH unusual methods are necessary for execution of the Work,the Contractor shall exercise utmost RESPECT TO ITS COMPLETION OR care and carry on such activities under supervision of properly qualified personnel. MODIFICATION.AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA 10.2.5 The Contractor shall promptly remedy damage and loss (other than damage or loss DOCUMENT MAY BE MADE BY USING AIA insured under property insurance required by the Contract Documents)to property referred to DOCUMENT D401. in Clauses 10.2.1.2 and 10.2.1.3 caused in whole or in part by the Contractor,a Subcontractor,a Sub-subcontractor,or anyone directly or indirectly employed by any of them,or by anyone for This document has been approved and whose acts they may be liable and for which the Contractor is responsible under Clauses 10.2.1.2 endorsed by The Associated General and 10.2.1.3,except damage or loss attributable to acts or omissions of the Owner or Architect or Contractors of America. anyone directly or indirectly employed by either of them,or by anyone for whose acts either of them may be liable, and not attributable to the fault or negligence of the Contractor. The foregoing obligations of the Contractor are in addition to the Contractor's obligations under Paragraph 3.18. 10.2.6 The Contractor shall designate a responsible member of the Contractor's organization at the site whose duty shall be the prevention of accidents.This person shall be the Contractor's superintendent unless otherwise designated by the Contractor in writing to the Owner and Architect. 10.2.7 The Contractor shall not load or permit any part of the construction or site to be loaded so as to endanger its safety. 10.3 HAZARDOUS MATERIALS 10.3.1 If reasonable precautions will be inadequate to prevent foreseeable bodily injury or death to persons resulting from a material or substance,including but not limited to asbestos or polychlorinated biphenyl (PCB), encountered on the site by the Contractor, the Contractor shall, upon recognizing the condition,immediately stop Work in the affected area and report the condition to the Owner and Architect in writing. 10.3.2 The Owner shall obtain the services of a licensed laboratory to verify the presence or absence of the material or substance reported by the Contractor and,in the event such material or substance is found to be present, to verify that it has been rendered harmless. Unless otherwise required by the Contract Documents, the Owner shall furnish in writing to the ,� Contractor and Architect the names and qualifications of persons or entities who are to far+rlir•V" perform tests verifying the presence or absence of such material or substance or who are to r� perform the task of removal or safe containment of such material or substance.The Contractor and the Architect will promptly reply to the Owner in writing stating whether or not either has 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE >• opyrlg t 1911, 1915, 1918, 1925, 1937, , by e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia — 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 35 AWIN reasonable objection to the persons or entities proposed by the Owner. If either the Contractor or Architect has an objection to a person or entity proposed by the Owner, the Owner shall propose another to whom the Contractor and the Architect have no reasonable objection. When the material or substance has been rendered harmless, Work in the affected area shall resume upon written agreement of the Owner and Contractor. The Contract Time shall be extended appropriately and the Contract Sum shall be increased in the amount of the Contractor's reasonable additional costs of shut-down, delay and start-up, which adjustments shall be accomplished as provided in Article 7. 10.3.3 To the fullest extent permitted by law,the Owner shall indemnify and hold harmless the Contractor,Subcontractors,Architect,Architect's consultants and agents and employees of any of them from and against claims,damages,losses and expenses,including but not limited to attorneys' fees,arising out of or resulting from performance of the Work in the affected area if in fact the material or substance presents the risk of bodily injury or death as described in Subparagraph 10.31 and has not been rendered harmless,provided that such claim,damage,loss or expense is attributable to bodily injury, sickness, disease or death, or to injury to or THIS DOCUMENT HAS IMPORTANT LEGAL destruction of tangible property(other than the Work itself) and provided that such damage, CONSEOUENCES.CONSULTATION WITHAN loss or expense is not due to the sole negligence of a party seeking indemnity. ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR 10.4 The Owner shall not be responsible under Paragraph 10.3 for materials and substances MODIFICATION.AUTHENTICATION OF THIS brought to the site by the Contractor unless such materials or substances were required by the ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA Contract Documents. DOCUMENT MI. 10.5 If,without negligence on the part of the Contractor, the Contractor is held liable for This document has been approved and the cost of remediation of a hazardous material or substance solely by reason of performing endorsed by The Associated General Work as required by the Contract Documents,the Owner shall indemnify the Contractor for all Contractors of America. cost and expense thereby incurred. 10.6 EMERGENCIES 10.6.1 In an emergency affecting safety of persons or property, the Contractor shall act, at the Contractor's discretion, to prevent threatened damage, injury or loss. Additional compensation or extension of time claimed by the Contractor on account of an emergency shall be determined as provided in Paragraph 4.3 and Article 7. ARTICLE 11 INSURANCE AND BONDS 11.1 CONTRACTOR'S LIABILITY INSURANCE 11.1.1 The Contractor shall purchase from and maintain in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located such insurance as will protect the Contractor from claims set forth below which may arise out of or result from the Contractor's operations under the Contract and for which the Contractor may be legally liable, whether such operations be by the Contractor or by a Subcontractor or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable: 1 claims under workers' compensation, disability benefit and other similar employee benefit acts which are applicable to the Work to be performed; .2 claims for damages because of bodily injury,occupational sickness or disease,or death of the Contractor's employees; .3 claims for damages because of bodily injury,sickness or disease, or death of any person other than the Contractor's employees; .4 claims for damages insured by usual personal injury liability coverage; w., ,-W .5 claims for damages, other than to the Work itself, because of injury to or .W .W destruction of tangible property,including loss of use resulting therefrom; �r .6 claims for damages because of bodily injury, death of a person or property 01997 AIA® damage arising out of ownership,maintenance or use of a motor vehicle; AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 5, by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia — 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 36 .7 claims for bodily injury or property damage arising out of completed operations; and .8 claims involving contractual liability insurance applicable to the Contractor's obligations under Paragraph 318. 11.1.2 The insurance required by Subparagraph n.i.i shall be written for not less than limits of liability specified in the Contract Documents or required by law, whichever coverage is greater.Coverages,whether written on an occurrence or claims-made basis,shall be maintained without interruption from date of commencement of the Work until date of final payment and termination of any coverage required to be maintained after final payment. 11.1.3 Certificates of insurance acceptable to the Owner shall be filed with the Owner prior to commencement of the Work. These certificates and the insurance policies required by this Paragraph u.i shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least 3e 45 ys'prior written notice has been given to the THIS DOCUMENT HAS IMPORTANT LEGAL Owner. If any of the foregoing insurance coverages are required to remain in force after final CONSEQUENCES.CONSULTATION WITHAN payment and are reasonably available,an additional certificate evidencing continuation of such ATTORNEY 15 ENCOURAGED WITH coverage shall be submitted with the final Application for Payment as required by RESPECT TO ITS COMPLETION OR Subparagraph 9.10.2. Information concerning reduction of coverage on account of revised MODIFICATION.AUTHENTICATION OF T115 limits or claims paid under the General Aggregate,or both,shall be furnished by the Contractor ELECTRONICALLY DRAFTED AIA with reasonable promptness in accordance with the Contractor's information and belief. DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. 11.2 OWNER'S LIABILITY INSURANCE 11.2.1 The Owner shall be responsible for purchasing and maintaining the Owner's usual This document has been approved and endorsed by The Associated General liability insurance. Contractors of America. 11.3 PROJECT MANAGEMENT PROTECTIVE LIABILITY INSURANCE 11.3.1 Optionally, the Owner may require the Contractor to purchase and maintain Project Management Protective Liability insurance from the Contractor's usual sources as primary coverage for the Owners, Contractor's and Architect's vicarious liability for construction operations under the Contract. Unless otherwise required by the Contract Documents, the Owner shall reimburse the Contractor by increasing the Contract Sum to pay the cost of purchasing and maintaining such optional insurance coverage,and the Contractor shall not be responsible for purchasing any other liability insurance on behalf of the Owner.The minimum limits of liability purchased with such coverage shall be equal to the aggregate of the limits required for Contractor's Liability Insurance under Clauses 11.1.1.2 through u.1.1.5. 11.3.2 To the extent damages are covered by Project Management Protective Liability insurance,the Owner,Contractor and Architect waive all rights against each other for damages, except such rights as they may have to the proceeds of such insurance.The policy shall provide for such waivers of subrogation by endorsement or otherwise. 11.3.3 The Owner shall iket-require the Contractor to include the Owner,Ar-ehiteet or.et peeset3sntities as-1 additional insureds-on the Contractor's Liability Insurance coverage under Paragraph li.i. 11.4 PROPERTY INSURANCE 11.4.1 Unless otherwise provided,the Owner shall purchase and maintain,in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located, property insurance written on a builder's risk"all-risk"or equivalent policy form in the amount •. • - .• of the initial Contract Sum, plus value of subsequent Contract modifications and cost of materials supplied or installed by others,comprising total value for the entire Project at the site on a replacement cost basis without optional deductibles. Such property insurance shall be 01997 AIAO maintained, unless otherwise provided in the Contract Documents or otherwise agreed in AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 9 18, 1925, 1937, 1951, 1958, 1961, 9 y The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 37 writing by all persons and entities who are beneficiaries of such insurance, until final payment has been made as provided in Paragraph gao or until no person or entity other than the Owner has an insurable interest in the property required by this Paragraph 11.4 to be covered, whichever is later. This insurance shall include interests of the Owner, the Contractor, Subcontractors and Sub-subcontractors in the Project. 11.4.1.1 Property insurance shall be on an "all-risk" or equivalent policy form and shall include, without limitation, insurance against the perils of fire (with extended coverage) and physical loss or damage including,without duplication of coverage,theft,vandalism,malicious mischief, collapse, earthquake, flood, windstorm, falsework, testing and startup, temporary buildings and debris removal including demolition occasioned by enforcement of any applicable legal requirements, and shall cover reasonable compensation for Architect's and Contractor's services and expenses required as a result of such insured loss. 11.4.1.2 If the Owner does not intend to purchase such property insurance required by the Contract and with all of the coverages in the amount described above, the Owner shall so THIS DOCUMENT HAS IMPORTANT LEGAL inform the Contractor in writing prior to commencement of the Work. The Contractor may CONSEOUENCES.CONSULTATION WITH AN then effect insurance which will protect the interests of the Contractor, Subcontractors and ATTORNEY IS ENCOURAGED WITH Sub-subcontractors in the Work, and by appropriate Change Order the cost thereof shall be RESPECT TO ITS COMPLETION OR charged to the Owner. If the Contractor is damaged b the failure or neglect of the Owner to MODIFICATION.AUTHENTICATION OF THIS r$ g Y g ELECTRONICALLY DRAFTED AIA purchase or maintain insurance as described above, without so notifying the Contractor in DOCUMENT MAY BE MADE BY USING AIA writing,then the Owner shall bear all reasonable costs properly attributable thereto. DOCUMENT D401. 11.4.1.3 If the property insurance requires deductibles, the Owner shall pay costs not This document has been approved and covered because of such deductibles. endorsed by The Associated General Contractors of America. 11.4.1.4 This property insurance shall cover portions of the Work stored off the site,and also portions of the Work in transit. 11.4.1.5 Partial occupancy or use in accordance with Paragraph 9.9 shall not commence until the insurance company or companies providing property insurance have consented to such partial occupancy or use by endorsement or otherwise. The Owner and the Contractor shall take reasonable steps to obtain consent of the insurance company or companies and shall, without mutual written consent,take no action with respect to partial occupancy or use that would cause cancellation,lapse or reduction of insurance. 11.4.2 Boiler and Machinery Insurance. The Owner shall purchase and maintain boiler and machinery insurance required by the Contract Documents or by law, which shall specifically cover such insured objects during installation and until final acceptance by the Owner, this insurance shall include interests of the Owner, Contractor, Subcontractors and Sub-subcontractors in the Work,and the Owner and Contractor shall be named insureds. 11.4.3 Loss of Use Insurance. The Owner, at the Owner's option, may purchase and maintain such insurance as will insure the Owner against loss of use of the Owner's property due to fire or other hazards,however caused.The Owner waives all rights of action against the Contractor for loss of use of the Owner's property,including consequential losses due to fire or other hazards however caused. 11.4.4 If the Contractor requests in writing that insurance for risks other than those described herein or other special causes of loss be included in the property insurance policy,the Owner shall,if possible,include such insurance,and the cost thereof shall be charged to the Contractor ff by appropriate Change Order. 11.4.5 If during the Project construction period the Owner insures properties, real or e1997 Ame personal or both,at or adjacent to the site by property insurance under policies separate from AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE >, opyng t 5, 9 y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 121312002. AIA License Number 1008538, which expires on 9/3/2003. 38 those insuring the Project,or if after final payment property insurance is to be provided on the completed Project through a policy or policies other than those insuring the Project during the construction period, the Owner shall waive all rights in accordance with the terms of Subparagraph 11.4.7 for damages caused by fire or other causes of loss covered by this separate property insurance. All separate policies shall provide this waiver of subrogation by endorsement or otherwise. 11.4.6 Before an exposure to loss may occur,the Owner shall file with the Contractor a copy of each policy that includes insurance coverages required by this Paragraph 11.4. Each policy shall contain all generally applicable conditions, definitions, exclusions and endorsements related to this Project.Each policy shall contain a provision that the policy will not be canceled or allowed to expire,and that its limits will not be reduced,until at least 3o days'prior written notice has been given to the Contractor. 11.4.7 Waivers of Subrogation. The Owner and Contractor waive all rights against (1) each other and any of their subcontractors,sub-subcontractors,agents and employees,each of THIS DOCUMENT HAS IMPORTANT LEGAL the other, and (2) the Architect, Architect's consultants, separate contractors described in CONSEQUENCES.CONSULTATION WITH AN Article 6,if any,and any of their subcontractors,sub-subcontractors,agents and employees,for ATTORNEY IS ENCOURAGED WITH damages caused by fire or other causes of loss to the extent covered by property insurance RESPECT TO ITS COMPLETION OR obtained pursuant to this Paragraph 11.4 or other property insurance applicable to the Work, MODIFICATION.AUTHENTICATION OF THIS except such rights as they have to proceeds of such insurance held by the Owner as fiduciary. ELECTRONICALLY DRAFTED DOCUMENT MAY BE MADE BY AIA BY The Owner or Contractor,as appropriate,shall require of the Architect,Architect's consultants, USING AIA DOCUMENT D401. separate contractors described in Article 6,if any, and the subcontractors,sub-subcontractors, agents and employees of any of them, by appropriate agreements, written where legally This document has been approved and required for validity, similar waivers each in favor of other parties enumerated herein. The endorsed by The Associated General policies shall provide such waivers of subrogation by endorsement or otherwise. A waiver of Contractors of America. subrogation shall be effective as to a person or entity even though that person or entity would otherwise have a duty of indemnification,contractual or otherwise,did not pay the insurance premium directly or indirectly, and whether or not the person or entity had an insurable interest in the property damaged. 11.4.8 A loss insured under Owner's properly insurance shall be adjusted by the Owner as fiduciary and made payable to the Owner as fiduciary for the insureds, as their interests may appear,subject to requirements of any applicable mortgagee clause and of Subparagraph 11.4.10. The Contractor shall pay Subcontractors their just shares of insurance proceeds received by the Contractor, and by appropriate agreements, written where legally required for validity, shall require Subcontractors to make payments to their Sub-subcontractors in similar manner. 11.4.9 If required in writing by a party in interest, the Owner as fiduciary shall, upon occurrence of an insured loss, give bond for proper performance of the Owner's duties. The cost of required bonds shall be charged against proceeds received as fiduciary.The Owner shall deposit in a separate account proceeds so received, which the Owner shall distribute in accordance with such agreement as the parties in interest may reach,or in accordance with an arbitration award in which case the procedure shall be as provided in Paragraph 4.6. If after such loss no other special agreement is made and unless the Owner terminates the Contract for convenience, replacement of damaged property shall be performed by the Contractor after notification of a Change in the Work in accordance with Article 7. 11.4.10 The Owner as fiduciary shall have power to adjust and settle a loss with insurers unless one of the parties in interest shall object in writing within five days after occurrence of loss to the Owner's exercise of this power, if such objection is made, the dispute shall be resolved as provided in Paragraphs 4.5 and 4.6. The Owner as fiduciary shall, in the case of arbitration, J;,+yjr�'�.� make settlement with insurers in accordance with directions of the arbitrators.If distribution of insurance proceeds by arbitration is required,the arbitrators will direct such distribution. 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE s opyng t 1911, 1915, 1918, 1925, 1937, , 1967, y e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution. WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia — 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 39 '11111110 4 11.5 PERFORMANCE BOND AND PAYMENT BOND 11.5.1 The Owner shall have the right to require the Contractor to furnish bonds covering faithful performance of the Contract and payment of obligations arising thereunder as stipulated in bidding requirements or specifically required in the Contract Documents on the date of execution of the Contract. 11.5.2 Upon the request of any person or entity appearing to be a potential beneficiary of bonds covering payment of obligations arising under the Contract, the Contractor shall promptly furnish a copy of the bonds or shall permit a copy to be made. ARTICLE 12 UNCOVERING AND CORRECTION OF WORK 12.1 UNCOVERING OF WORK 12.1.1 If a portion of the Work is covered contrary to the Architect's request or to requirements specifically expressed in the Contract Documents, it must,if required in writing by the Architect, be uncovered for the Architect's examination and be replaced at the THIS DOCUMENT HAS IMPORTANT LEGAL Contractors expense without change in the Contract Time. CONSEQUENCES.CONSULTATION WITH AN ATTORNEY 15 ENCOURAGED WITH 12.1.2 If a portion of the Work has been covered which the Architect has not specifically RESPECT TO ITS COMPLETION OR requested to examine prior to its being covered, the Architect may request to see such Work MODIFICATION.AUTHENTICATION OF THIS and it shall be uncovered by the Contractor. If such Work is in accordance with the Contract ELECTRONICALLY DRAFTED AIA Documents,costs of uncovering and replacement shall,by appropriate Change Order,be at the DOCUMENT MAY BE MADE BY USING AIA Owner's expense. If such Work is not in accordance with the Contract Documents,correction DOCUMENT MI, shall be at the Contractor's expense unless the condition was caused by the Owner or a separate This document has been approved and contractor in which event the Owner shall be responsible for payment of such costs. endorsed by The Associated General 12.2 CORRECTION OF WORK Contractors of America. 12.2.1 BEFORE OR AFTER SUBSTANTIAL COMPLETION 12.2.1.1 The Contractor shall promptly correct Work rejected by the Architect or failing to conform to the requirements of the Contract Documents, whether discovered before or after Substantial Completion and whether or not fabricated, installed or completed. Costs of correcting such rejected Work,including additional testing and inspections and compensation for the Architect's services and expenses made necessary thereby, shall be at the Contractor's expense. 12.2.2 AFTER SUBSTANTIAL COMPLETION 12.2.2.1 In addition to the Contractor's obligations under Paragraph 3.5,if,within one year after the date of Substantial Completion of the Work or designated portion thereof or after the date for commencement of warranties established under Subparagraph 9.9.1,or by terms of an applicable special warranty required by the Contract Documents, any of the Work is found to be not in accordance with the requirements of the Contract Documents,the Contractor shall correct it promptly after receipt of written notice from the Owner to do so unless the Owner has previously given the Contractor a written acceptance of such condition. The Owner shall give such notice promptly after discovery of the condition. During the one-year period for correction of Work, if the Owner fails to notify the Contractor and give the Contractor an opportunity to make the correction, the Owner waives the rights to require correction by the Contractor and to make a claim for breach of warranty. If the Contractor fails to correct nonconforming Work within a reasonable time during that period after receipt of notice from the Owner or Architect,the Owner may correct it in accordance with Paragraph 2.4. 12.2.2.2 The one-year period for correction of Work shall be extended with respect to A portions of Work first performed after Substantial Completion by the period of time between Substantial Completion and the actual performance of the Work. 01"7 AIAO AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE s opyrig t 1911, 1915, 9 , by a CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 40 12.2.2.3 The one-year period for correction of Work shall not be extended by corrective Work performed by the Contractor pursuant to this Paragraph 12.2. 12.2.3 The Contractor shall remove from the site portions of the Work which are not in accordance with the requirements of the Contract Documents and are neither corrected by the Contractor nor accepted by the Owner. 12.2.4 The Contractor shall bear the cost of correcting destroyed or damaged construction, whether completed or partially completed,of the Owner or separate contractors caused by the Contractor's correction or removal of Work which is not in accordance with the requirements of the Contract Documents. 12.2.5 Nothing contained in this Paragraph 12.2 shall be construed to establish a period of limitation with respect to other obligations which the Contractor might have under the Contract Documents.Establishment of the one-year period for correction of Work as described THIS DOCUMENT HAS IMPORTANT LEGAL in Subparagraph 12.2.2 relates only to the specific obligation of the Contractor to correct the CONSEQUENCES.CONSULTATION WITHAN Work, and has no relationship to the time within which the obligation to comply with the ATTORNEY 15 ENCOURAGED WITH Contract Documents may be sought to be enforced,nor to the time within which proceedings RESPECT TO ITS COMPLETION OR may be commenced to establish the Contractor's liability with respect to the Contractor's MODIFICATION.AUTHENTICATION OF THIS obligations other than specifically to correct the Work. ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA 12.3 ACCEPTANCE OF NONCONFORMING WORK DOCUMENT D401. 12.3.1 If the Owner prefers to accept Work which is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and This document has been approved and correction,in which case the Contract Sum will be reduced as appropriate and equitable.Such endorsed by The Associated General adjustment shall be effected whether or not final payment has been made. Contractors of America. ARTICLE 13 MISCELLANEOUS PROVISIONS 13.1 GOVERNING LAW 13.1.1 The Contract shall be governed by the law of the place where the Project is located. 13.2 SUCCESSORS AND ASSIGNS 13.2.1 The Owner and Contractor respectively bind themselves, their partners, successors, assigns and legal representatives to the other party hereto and to partners, successors, assigns and legal representatives of such other party in respect to covenants, agreements and obligations contained in the Contract Documents. Except as provided in Subparagraph 13.2.2, neither party to the Contract shall assign the Contract as a whole without written consent of the other.If either party attempts to make such an assignment without such consent,that party shall nevertheless remain legally responsible for all obligations under the Contract. 13.2.2 The Owner may, without consent of the Contractor, assign the Contract to an institutional lender providing construction financing for the Project. In such event,the lender shall assume the Owner's rights and obligations under the Contract Documents. The Contractor shall execute all consents reasonably required to facilitate such assignment. 13.3 WRITTEN NOTICE 13.3.1 Written notice shall be deemed to have been duly served if delivered in person to the individual or a member of the firm or entity or to an officer of the corporation for which it was intended, or if delivered at or sent by registered or certified mail to the last business address known to the party giving notice. 13.4 RIGHTS AND REMEDIES 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1958, 1961, 1963, 1966, 1967, 1970, 1976, 1987, 0 1997 by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/3/2003. 41 13.4.1 Duties and obligations imposed by the Contract Documents and rights and remedies available thereunder shall be in addition to and not a limitation of duties, obligations, rights and remedies otherwise imposed or available by law. 13.4.2 No action or failure to act by the Owner, Architect or Contractor shall constitute a waiver of a right or duty afforded them under the Contract,nor shall such action or failure to act constitute approval of or acquiescence in a breach thereunder,except as may be specifically agreed in writing. 13.5 TESTS AND INSPECTIONS 13.5.1 Tests, inspections and approvals of portions of the Work required by the Contract Documents or by laws, ordinances, rules, regulations or orders of public authorities having jurisdiction shall be made at an appropriate time. Unless otherwise provided, the Contractor shall make arrangements for such tests,inspections and approvals with an independent testing laboratory or entity acceptable to the Owner,or with the appropriate public authority,and shall THIS DOCUMENT HAS IMPORTANT LEGAL bear all related costs of tests,inspections and approvals.The Contractor shall give the Architect CONSEQUENCES.CONSULTATION WITH AN timely notice of when and where tests and inspections are to be made so that the Architect may ATTORNEY IS ENCOURAGED WITH be present for such procedures. The Owner shall bear costs of tests, inspections or approvals RESPECT TO ITS COMPLETION OR which do not become requirements until after bids are received or negotiations concluded. MODIFICATION.AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA 13.5.2 If the Architect, Owner or public authorities having jurisdiction determine that DOCUMENT MAY BE MADE BY USING AIA portions of the Work require additional testing, inspection or approval not included under DOCUMENT D401. Subparagraph 13.5.1,the Architect will,upon written authorization from the Owner,instruct the Contractor to make arrangements for such additional testing, inspection or approval by an This document has been approved and entity acceptable to the Owner,and the Contractor shall give timely notice to the Architect of endorsed by The Associated General when and where tests and inspections are to be made so that the Architect may be present for Contractors of America. such procedures. Such costs,except as provided in Subparagraph 13.5.3,shall be at the Owner's expense. 13.5.3 If such procedures for testing,inspection or approval under Subparagraphs 13.51 and 13.5.2 reveal failure of the portions of the Work to comply with requirements established by the Contract Documents, all costs made necessary by such failure including those of repeated procedures and compensation for the Architect's services and expenses shall be at the Contractor's expense. 13.5.4 Required certificates of testing,inspection or approval shall,unless otherwise required by the Contract Documents, be secured by the Contractor and promptly delivered to the Architect. 13.5.5 If the Architect is to observe tests, inspections or approvals required by the Contract Documents, the Architect will do so promptly and,where practicable, at the normal place of testing. 13.5.6 Tests or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid unreasonable delay in the Work. 13.6 INTEREST 13.6.1 Payments due and unpaid under the Contract Documents shall bear interest from the date payment is due at such rate as the parties may agree upon in writing or, in the absence thereof,at the legal rate prevailing from time to time at the place where the Project is located. ;f++ � 13.7 COMMENCEMENT OF STATUTORY LIMITATION PERIOD 13.7.1 As between the Owner and Contractor. 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 1925, 9 by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 12/312002. AIA License Number 1008538, which expires on 9/312003. 42 .1 Before Substantial Completion. As to acts or failures to act occurring prior to the relevant date of Substantial Completion, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than such date of Substantial Completion; .2 Between Substantial Completion and Final Certificate for Payment. As to acts or failures to act occurring subsequent to the relevant date of Substantial Completion and prior to issuance of the final Certificate for Payment, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the date of issuance of the final Certificate for Payment;and .3 After Final Certificate for Payment. As to acts or failures to act occurring after the relevant date of issuance of the final Certificate for Payment, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the date of any act or failure to act by the Contractor pursuant to any Warranty THIS DOCUMENT HAS IMPORTANT LEGAL provided under Paragraph CONSEQUENCES.CONSULTATION WITHAN 1? i; p 3.5�the date of any correction of the Work or failure to correct the Work by the Contractor under Paragraph 12.2, or the date of actual ATTORNEY IS ENCOURAGED WITH RESORT TO ITS COMPLETION OR commission of any other act or failure to perform any duty or obligation by the MODIFICATION.AUTHENTICATION OF TMS Contractor or Owner,whichever occurs last. ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA ARTICLE 14 TERMINATION OR SUSPENSION OF THE CONTRACT DOCUMENT D401. 14.1 TERMINATION BY THE CONTRACTOR 14.1.1 The Contractor may terminate the Contract if the Work is stopped for a period of 30 This document has been approved and consecutive days through no act or fault of the Contractor or a Subcontractor, Sub- endorsed by The Associated General subcontractor or their agents or employees or any other persons or entities performing portions Contractors of America, of the Work under direct or indirect contract with the Contractor, for any of the following reasons: 1 issuance of an order of a court or other public authority having jurisdiction which requires all Work to be stopped; .2 an act of government,such as a declaration of national emergency which requires all Work to be stopped; .3 because the Architect has not issued a Certificate for Payment and has not notified the Contractor of the reason for withholding certification as provided in Subparagraph 9.4.1,.or because the Owner has not made payment on a Certificate for Payment within the time stated in the Contract Documents;or .4 the Owner has failed to furnish to the Contractor promptly, upon the Contractor's request,reasonable evidence as required by Subparagraph 2.2.1. 14.1.2 The Contractor may terminate the Contract if, through no act or fault of the Contractor or a Subcontractor, Sub-subcontractor or their agents or employees or any other persons or entities performing portions of the Work under direct or indirect contract with the Contractor, repeated suspensions,delays or interruptions of the entire Work by the Owner as described in Paragraph 14.3 constitute in the aggregate more than 100 percent of the total number of days scheduled for completion,or 12o days in any 365-day period,whichever is less. 14.1.3 If one of the reasons described in Subparagraph 14.1.1 or 14.1.2 exists, the Contractor may,upon seven days'written notice to the Owner and Architect,terminate the Contract and recover from the Owner payment for Work executed and for proven loss with respect to materials,equipment,tools,and construction equipment and machinery,including reasonable , overhead,profit and damages. f,''i�1"r•+r,` 14.1.4 If the Work is stopped for a period of 6o consecutive days through no act or fault of 01997 AIA® the Contractor or a Subcontractor or their agents or employees or any other persons performing AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 11951,911, 1915, 1918, 1987, V 1997 by e CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 43 portions of the Work under contract with the Contractor because the Owner has persistently failed to fulfill the Owner's obligations under the Contract Documents with respect to matters important to the progress of the Work, the Contractor may, upon seven additional days' written notice to the Owner and the Architect, terminate the Contract and recover from the Owner as provided in Subparagraph 14.1.3. 14.2 TERMINATION BY THE OWNER FOR CAUSE 14.2.1 The Owner may terminate the Contract if the Contractor: .1 persistently or repeatedly refuses or fails to supply enough properly skilled workers or proper materials; .2 fails to make payment to Subcontractors for materials or labor in accordance with the respective agreements between the Contractor and the Subcontractors; .3 persistently disregards laws,ordinances,or rules,regulations or orders of a public authority having jurisdiction;or .4 otherwise is guilty of substantial breach of a provision of the Contract THIS DOCUMENT HAS IMPORTANT LEGAL Documents. CONSEQUENCES.CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH 14.2.2 When any of the above reasons exist,the Owner, upon certification by the Architect RESPECT TO ITS COMPLETION OR that sufficient cause exists to justify such action,may without prejudice to any other rights or MODIFICATION.AUTHENTICATION OF THIS remedies of the Owner and after giving the Contractor and the Contractor's surety, if any, ELECTRONICALLY DRAFTED AIA seven days'written notice, terminate employment of the Contractor and may, subject to any DOCUMENT MAY BE MADE BY USING AIA prior rights of the surety: DOCUMENT D401. .1 take possession of the site and of all materials,equipment,tools,and construction This document has been approved and equipment and machinery thereon owned by the Contractor, endorsed by The Associated General .2 accept assignment of subcontracts pursuant to Paragraph 5.4;and Contractors of America. .3 finish the Work by whatever reasonable method the Owner may deem expedient. Upon request of the Contractor, the Owner shall furnish to the Contractor a detailed accounting of the costs incurred by the Owner in fmishing the Work. 14.2.3 When the Owner terminates the Contract for one of the reasons stated in Subparagraph 14.2.1, the Contractor shall not be entitled to receive further payment until the Work is finished. 14.2.4 If the unpaid balance of the Contract Sum exceeds costs of finishing the Work, including compensation for the Architect's services and expenses made necessary thereby,and other damages incurred by the Owner and not expressly waived,such excess shall be paid to the Contractor. If such costs and damages exceed the unpaid balance,the Contractor shall pay the difference to the Owner. The amount to be paid to the Contractor or Owner,as the case may be,shall be certified by the Architect, upon application, and this obligation for payment shall survive termination of the Contract. 14.3 SUSPENSION BY THE OWNER FOR CONVENIENCE 14.3.1 The Owner may,without cause,order the Contractor in writing to suspend,delay or interrupt the Work in whole or in part for such period of time as the Owner may determine. 14.3.2 The Contract Sum and Contract Time shall be adjusted for increases in the cost and time caused by suspension, delay or interruption as described in Subparagraph 14.3.1. Adjustment of the Contract Sum shall include profit. No adjustment shall be made to the extent: .1 that performance is,was or would have been so suspended,delayed or interrupted , by another cause for which the Contractor is responsible;or .2 that an equitable adjustment is made or denied under another provision of the Contract. 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright by The CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 gent conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 44 14.4 TERMINATION BY THE OWNER FOR CONVENIENCE 14.4.1 The Owner may,at any time,terminate the Contract for the Owner's convenience and without cause. 14.4.2 Upon receipt of written notice from the Owner of such termination for the Owner's convenience,the Contractor shall: .1 cease operations as directed by the Owner in the notice; .2 take actions necessary, or that the Owner may direct, for the protection and preservation of the Work;and .3 except for Work directed to be performed prior to the effective date of termination stated in the notice,terminate all existing subcontracts and purchase orders and enter into no further subcontracts and purchase orders. 14.4.3 In case of such termination for the Owner's convenience, the Contractor shall be THIS DOCUMENT HAS IMPORTANT LEGAL entitled to receive payment for Work executed, and costs incurred by reason of such CONSEOUENCES.CONSULTATION WITH AN termination,along with reasonable overhead and profit on the Work not executed. ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION.AUTHENTICATION OF TH1S ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. This document has been approved and endorsed by The Associated General Contractors of America. g A 01997 AIA® AIA DOCUMENT A201-1997 GENERAL CONDITIONS OF THE *Copyright 5, 1937, 1951, by The'CONTRACT FOR CONSTRUCTION American Institute of Architects. Fifteenth Edition. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United The American Institute of Architects States and will subject the violate to legal prosecution.WARNING: Unlicensed photocopying violates U.S. 1735 New York Avenue,N.W. copyright laws and will subject the violator to legal prosecution.This document was electronically produced Washington,D.C.20006-5292 with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. expiration as noted below. User Document: fs 12 A201 genl conditions.aia -- 12/3/2002. AIA License Number 1008538, which expires on 9/3/2003. 45 City of Renton/Renton Fire Department Fire Station 12 October 21,2002 SUPPLEMENTARY CONDITIONS 1.01 GENERAL A. General Conditions: The following supplements modify the"General Conditions of the Contract for Construction", AIA Document A201, 1997 edition,copyrighted by the American Institute of Architects is a part of these Contract Documents; Contractor and all subcontractors shall read and be governed by them. B. Modifications to the"General Conditions": Where a portion of the General Conditions is modified or deleted by these Supplementary Conditions,the unaltered portions of the General Conditions shall remain in effect. The following modifications include: 1. Requirements contained in Division 1 and other specification sections further define the requirements of the General and Supplementary Conditions. 2. REPLACE 11.4 through 11.5 with the following: "Builder's Risk insurance covering interests of the City,the Contractor, Subcontractors and Sub subcontractors in the Work shall be provided by the Contractor. Builder's Risk insurance shall be on an"all-risk"policy form, and shall insure against the perils of fire and extended coverage and physical loss or damage, including flood and earthquake,theft,vandalism,malicious mischief,collapse,temporary buildings and debris removal.The Builder's Risk insurance covering the work will have a deductible of$5,000 for each occurrence,which will be the responsibility of the Contractor.Higher deductibles for flood and earthquake perils may be accepted by the City upon written request by the Contractor and written acceptance by the City.Any increased deductibles accepted by the City will remain the responsibility of the Contractor.The Builder's Risk insurance shall be maintained until Final Acceptance of the Work by the City." 3. Item 11.1.3, the number of days of prior written notice is modified from 30 to 45 days. 4. Item 11.3.3 is modified to read,"The Owner shall require the Contractor to include the Owner as an additional insured on the Contractor's Liability Insurance coverage under Paragraph 11.1." END OF SECTION 00800-Supplementary Conditions-Page 1